1 READY RECKNER CHART NO. 1.3.8 RATE RS. 36,500/- PER SQ. MTRS. CARPET AREA OF FLAT _________ SQ. MTRS. and usable area of Balconies+ utility + C/B of _________Sq. Mtrs. AREA OF PARKING _______ SQ. MTRS. CONSIDERATION RS. ___________________ MARKET VALUE RS. _________________ STAMP RS. ________________ + 1% surcharge Rs. _____________- = _____________________. AGREEMENT OF SALE THIS AGREEMENT OF SALE is made & executed at Nashik on this ____ day of JULY 2017. BETWEEN MR. ______________________________________________________________, Age ______ Years, Occupation __________, PAN ____________________ R/o. _______________________________________________________________ hereinafter called the “Allottee/s/Purchaser/S” (which expression shall unless repugnant to the context or meaning thereof be deemed to mean and include his/her heirs, executors, administrators, successors-in-interest and permitted assignees). OF THE FIRST PART AND MRS. MANISHA VISHNU RANE, Age 41 Years, Occupation Business, R/o. Flat No. 2, Govind Park, Untwadi, Nashik 422 009, PAN AEHPR 7441 D, Hereinafter referred to as the "VENDOR/PROMOTER" (Which expression shall unless it be repugnant to the context or meaning thereof mean and include its other partners, executors, administrators, assigns, etc.) of the FIRST PART . WHEREAS the Vendor /promoter is the absolute & exclusive owner & otherwise is well & sufficiently entitled to all that piece & parcel of the land situated at Nashik, more particularly described in the first schedule written hereunder and hereinafter referred to as the SAID LAND. AND WHEREAS the vendor /promoter has purchased Plot No. 13 from the previous owner Mrs. Nivrutti Balu Jagtap and others by Sale deed Dated 10- 10-2012 which is duly registered at the office of Sub Registrar, Nashik 3 at Sr. No. 9884 on 11-10-2012 and name of the vendor /promoter is mutated in the owners column of the record of rights and since then the vendor /promoter is in actual possession and enjoyment of the said property as absolute and exclusive owner thereof. AND WHEREAS the vendor /promoter has purchased Plot No. 14 from the previous owner Mrs. Nivrutti Balu Jagtap and others by Sale deed Dated 10- 10-2012 which is duly registered at the office of Sub Registrar, Nashik 3 at Sr. No. 9895 on 12-10-2012 and name of the vendor /promoter is mutated in the owners column of the record of rights and since then the vendor /promoter is in actual possession and enjoyment of the said property as absolute and exclusive owner thereof. AND WHEREAS the vendor/ promoter has purchased TDR of 129-00 Sq. Mtrs. from DRC No. 297 Dated 8-6-2009 from Mr. Mohan Chetandas Malwani and Mr. Harilal Asanand Therani by a sale deed Dated 3-11-2012 which is duly registered at the office of Sub Registrar, Nashik 3 at Sr. No. 10610 on 5-11-2012 and the vendor/ promoter has purchased TDR of 40-00 Sq. Mtrs. from DRC No. 476 Dated 5-5-2011 from M/s. Shweta Infrastructure and Housing (I) Pvt. Ltd. by a sale deed Dated 3-11-2012 which is duly registered at the office of Sub Registrar, Nashik 3 at Sr. No. 10608 on 5-11-2012 and the vendor / promoter prepared a building plan by 2 amalgamating both plots which is duly approved by Nashik Municipal Corporation under commencement certificate N0. LND/BP/WS/CD/ B3 / 523/ 4794 dated 13-12-2012 and as per the building plan the vendor has commenced the construction on the said property. AND WHEREAS the Promoter is entitled and enjoined upon to construct buildings on the project land in accordance with the recitals hereinabove; AND WHEREAS the Vendor/Promoter is in possession of the project land. AND WHEREAS the Promoter has proposed to construct on the project land one Building Consisting of Stilt for Parking and first to Fourth upper floors as per approved building plan. AND WHEREAS the Allottee is offered an Apartment bearing number __________ on the ____________ floor, (herein after referred to as the said “Apartment”) in the Building called SRI GURUMANGAL APARTMENT (herein after referred to as the said “Building”) being constructed on the said property, by the Promoter, the said apartment is more particularly described in the second schedule/ Annexure A written hereunder. AND WHEREAS the Promoter has appointed a structural Engineer M/S. DELTACOM STRUCTURAL CONSULTANTS for the preparation of the structural design and drawings of the buildings and the Promoter accepts the professional supervision of the Architect and the structural Engineer till the completion of the building/ buildings. AND WHEREAS by virtue of the Sale Deed the Promoter has sole and exclusive right to sell the Apartments in the said building/s to be constructed by the Promoter on the project land and to enter into Agreement/s with the allottee(s)/s of the Apartments to receive the sale consideration in respect thereof; AND WHEREAS on demand from the allottee, the Promoter has given inspection to the Allottee of all the documents of title relating to the project land and the plans, designs and specifications prepared by the Promoter's Architects and of such other documents as are specified under the Real Estate (Regulation and Development) Act 2016 (hereinafter referred to as "the said Act") and the Rules and Regulations made thereunder; AND WHEREAS the authenticated copies of Certificate of Title issued by the advocate of the Promoter, authenticated copies of Property card or extract of Village Forms VI and VII and XII or any other relevant revenue record showing the nature of the title of the Promoter to the project land on which the Apartments are constructed or are to be constructed have been annexed hereto and marked as Annexure 'A' and 'B', respectively. AND WHEREAS the authenticated copies of the plans of the construction as proposed by the Promoter and according to which the construction of the buildings and open spaces are proposed to be provided for on the said project have been annexed hereto and marked as Annexure C. AND WHEREAS the authenticated copies of the plans and specifications of the Apartment agreed to be purchased by the Allottee, 3 as sanctioned and approved by the local authority have been annexed and marked as Annexure D. AND WHEREAS the Promoter has got some of the approvals from the concerned local authority(s) to the plans, the specifications, elevations, sections and of the said building/s and shall obtain the balance approvals from various authorities from time to time, so as to obtain Building Completion Certificate or Occupancy Certificate of the said Building. AND WHEREAS while sanctioning the said plans concerned local authority and/or Government has laid down certain terms, conditions, stipulations and restrictions which are to be observed and performed by the Promoter while developing the project land and the said building and upon due observance and performance of which only the completion or occupancy certificate in respect of the said building/s shall be granted by the concerned local authority. AND WHEREAS the vendor/promoter has informed the purchasers that though the building plan is approved by Nashik Municipal Corporation on the basis of the area of the said property consisting of Stilt for Parking and First to Fourth Floors by using the TDR on the said property, the vendor /promoter intends to obtain TDR and take all the benefits as may be made available on the said property for additional construction in view of the new DC rules to be applicable and as such the vendor / promoter shall be entitled to revise and amend the building plan by using and utilising the TDR and in such case additional floors shall be sanctioned by Nashik Municipal Corporation and as such all the benifts of the said additional floors or construction as may be made available on the said property to the vendor / promoter and the vendor/promoter shall have rights to construct such additional floors as may be sanctioned by NMC and the vendor shall be entitled to sell, alienate or dispose off the same and as such the purchasers gives his/their specific consent for the amendment and revision of the building plan. Provided always that the promoter shall take prior consent from the purchaser /allottees for amendment of the building plan of the area, location and size of the apartment of the purchaser/allottes is adversely affected. AND WHEREAS the Promoter has accordingly commenced construction of the said building/s in accordance with the said sanctioned plans. AND WHEREAS the Allottee has applied to the Promoter for allotment of an Apartment No. ___________ on __________floor in the building known as SRI GURUMANGAL APARTMENT. AND WHEREAS the carpet area of the said Apartment is ____________ SQ. MTRS. and absolute ownership in usable area of Balconies/ utility / C/B/ Terrace admeasuring _________ Sq. Mtrs. And AREA OF PARKING __________ SQ. MTRS. and "carpet area"as per RERA means the net usable floor area of an apartment, excluding the area covered by the external walls, areas under services shafts, exclusive balcony appurtenant to the said Apartment for exclusive use of the Allottee or verandah area and exclusive open terrace area appurtenant to the said Apartment for exclusive use of the Allottee, but includes the area covered by the internal partition walls of the apartment. 4 AND WHEREAS the allottee has independently made himself aware about the specifications provided by the promoter and he is aware of the limitations, usage policies and maintenance of the installed items, fixtures and fittings of the same and have been annexed and marked as Annexure G. AND WHEREAS the Parties relying on the confirmations, representations and assurances of each other to faithfully abide by all the terms, conditions and stipulations contained in this Agreement and all applicable laws, are now willing to enter into this Agreement on the terms and conditions appearing hereinafter; AND WHEREAS prior to the execution of these presents the Allottee has paid to the Promoter a sum of Rs. _____________ (Rupees ________ __________________ only) by Cheque __________ drawn on ___________ ____________________ Bank, Dated _____________ being part payment of the sale consideration of the Apartment agreed to be sold by the Promoter to the Allottee as advance payment or Application Fee (the payment and receipt whereof the Promoter hereby admit and acknowledge) and the Allottee has agreed to pay to the Promoter the balance of the sale consideration in the manner hereinafter appearing. AND WHEREAS under section 13 of the said Act the Promoter is required to execute a written Agreement for sale of said Apartment with the Allottee, being in fact these presents and also to register said Agreement under the Registration Act, 1908. AND WHEREAS the purchaser/allottee has independently verified the tilte of the said land, building plan, the specifications and amenities provided in the said building and common facilities as detailed by the promoter and the purchaser/allottee is satisfied about the same and after the satisfaction the purchaser has agreed to purchase the apartment from the promoter / vendor. In accordance with the terms and conditions set out in this Agreement and as mutually agreed upon by and between the Parties, the Promoter hereby agrees to sell and the Allottee hereby agrees to purchase the Apartment and the garage/covered parking(if applicable) as described herein after. NOW THEREFOR, THIS AGREEMENT WITNESSETH AND IT IS HEREBY AGREED BY AND BETWEEN THE PARTIES HERETO AS FOLLOWS:- 1. The Promoter shall initially construct the said building/s consisting of Stilt for parking and First Floor to Fourth Floor on the project land in accordance with the plans, designs and specifications as approved by the concerned local authority at present. Provided that the promoter shall have to obtain prior consent in writing of the allottee in respect of variations or modifications which may adversely affect the apartment of the allottee except any alteration or additions required by any Govt. Authorities or due to change in law. 1. a (i) The Allottee hereby agrees to purchase from the Promoter and the Promoter hereby agrees to sell to the Allottee Apartment No. ______admeasuring _________ Sq. Mtrs. and absolute ownership in usable area of Balconies/ utility / C/B/ Terrace admeasuring _________ Sq. Mtrs. And AREA OF PARKING __________ 5 SQ. MTRS. on __________ Floor in the said building (hereinafter referred to as "the Apartment") as shown in the Floor plan thereof hereto annexed and marked Annexures C for the consideration of Rs. ________________- including parking and the proportionate price of the common areas and facilities appurtenant to the premises, the nature, extent and description of the common areas and facilities which are more particularly described in the Schedule annexed herewith. (ii) The Allottee hereby agrees to purchase from the Promoter and the Promoter hereby agrees to sell to the Allottee parking spaces bearing No. _______ situated at stilt constructed in the layout building or as the local authority may have sanctioned on approval of the building plan for consideration of Rs. ________________. 1(b) The total aggregate consideration amount for the apartment including parking spaces is Rs. ___________________. 1(c) The Allottee has paid on or before execution of this agreement a sum of Rs. _____________- (Rupees ____________ ) only by Cheque ___________ drawn on __________________ Bank Dated ______________ as advance payment or application fee and hereby agrees to pay to that the Promoter the balance amount of Rs. ______________ (Rupees _______________________ only) in the following manner :- Rs. ______________- (Rs. ___________________ only) to be paid to the Promoter at the time of possession. 1(d) The Total Price above excludes Taxes (consisting of tax paid or payable by the Promoter by way of Value Added Tax, Service Tax, GST and Cess or any other similar taxes which may be levied, in connection with the construction of and carrying out the Project payable by the Promoter) up to the date of handing over the possession of the Apartment. 1(e) The Total Price is escalation-free, save and except escalations/ increases, due to increase on account of development charges payable to the competent authority and/or any other increase in charges which may be levied or imposed by the competent authority Local Bodies /Government from time to time. The Promoter undertakes and agrees that while raising a demand on the Allottee for increase in development charges, cost, or levies imposed by the competent authorities etc., the Promoter shall enclose the said notification/order/rule/regulation published / issued in that behalf to that effect along with the demand letter being issued to the Allottee, which shall only be applicable on subsequent payments. The Promoter may charge the allottee separately for any upgradation/changes specifically requested or approved by the allotte in fittings, fixtures and specification and any other facility which have been done on the allottee’s request. 1(f) The Promoter may allow, in its sole discretion, a rebate for early payments of equal instalments payable by the Allottee by discounting such early payments as the Promotor and 6 allottee may decide for the period by which the respective instalment has been preponed. 1(g) The Promoter shall confirm the final carpet area that has been allotted to the Allottee after the construction of the Building is complete and the occupancy certificate is granted by the competent authority, by furnishing details of the changes, if any, in the carpet area, subject to a variation cap of three percent. The total price payable for the carpet area shall be recalculated upon confirmation by the Promoter. If there is any reduction in the carpet area within the defined limit then Promoter shall refund the excess money paid by Allottee within forty-five days with annual interest at the rate specified in the Rules, from the date when such an excess amount was paid by the Allottee. If there is any increase in the carpet area allotted to Allottee, the Promoter shall demand additional amount from the Allottee as per the next milestone of the Payment Plan. All these monetary adjustments shall be made at the same rate per square meter as agreed in Clause 1(a) of this Agreement. 1(h) The Allottee authorizes the Promoter to adjust/appropriate all payments made by him/her under any head(s) of dues against lawful outstanding, if any, in his/her name as the Promoter may in its sole discretion deem fit and the Allottee undertakes not to object / demand / direct the Promoter to adjust his payments in any manner. 2.1The Promoter hereby agrees to observe, perform and comply with all the terms, conditions, stipulations and restrictions if any, which may have been imposed by the concerned local authority State and or central Govt. including Environmental department at the time of sanctioning the plans or any time thereafter or at the time of granting completion certificate or anytime thereafter. The promoter shall before handing over possession of the Apartment to the Allottee, obtain from the concerned local authority occupancy and/or completion certificates in respect of the Apartment. Notwithstanding anything to the contrary contained therein, the purchasers shall not be claim possession of the said premises the completion certificate is received from the local authority and the purchasers has paid all the dues payable under this agreement in respect of the said premises to the promoters and has paid the necessary maintenance amount/ deposit, GST and other taxes payable under this agreement of the said premises to the promoters. Howsoever for the purpose of defect liability on towards the promoters, the date shall be calculated from the date of handing over the possession to the purchasers for fit outs and interior works and that the said liability shall be those responsibilities which are not covered under maintenance of the said premises / building / phase/ wing as stated in the said agreement. That further it has been agreed by the purchasers that any damages or change done within the premises sold or in the building done by him or by any third person on behalf of he purchasers then the purchasers expressly absolves the promoters from the same liability and specifically consents that on such act done, he shall waive his right to enforce the defect liability on and towards the promoters. 7 2.2Time is essence for the Promoter as well as the Allottee. The Promoter shall abide by the time schedule for completing the project and handing over the Apartment to the allottee and common areas to association of the allottees after receiving the occupancy certificate or the completion certificate or both, as the case may be. Similarly, the Allote shall make timely payments of the installment and other dues payable by him / her and meeting the other obligation under the Agreement subject to the simultaneous completion of construction by the Promoter as provided in Clause herein above. (“Payment Plan”). 3. The Promoter hereby declares that the Floor Space Index available as on date in respect of the project land is 420-00 square meters only by availing of TDR of 168-00 Sq. Mtrs. and thus the promoter has utilized total FSI of 588-00 Sq. Mtrs. as per the Development Control Regulation. Apart from the TDI used by the promoter, additional TDR on the project land is available as on today as per the approved DC rules and promoter shall be entitled to use, utilize the said TDR and accordingly amend and modify the building plans as and when the promoter finds it necessary before the final completion and occupation certificate from Nashik Municipal Corporation. Provided that the promoter shall obtain the consent of the allottee for the said modifications and veriations if such variations and modifications adversely affect the apartment agreed to be purchased by the allottee. 4.1 The promoter has made full and true disclosure of the title of the said land as well as encumbrance, if any, known to the promoter in the title report of the advocate. The promoter has also disclosed to the allottee/ nature of its right, title and interest or right to construct building/s and also give inspection of all documents to the allottees, as required by the law. The allottee having acquainted himself with all facts and right of the promoter and after satisfaction of the same has entered into this agreement. 4.2If the Promoter fails to abide by the time schedule for completing the project and handing over the Plot to the Allottee, the Promoter agrees to pay to the Allottee, who does not intend to withdraw from the project, interest as specified in the Rule, on all the amounts paid by the Allottee, for every month of delay, till the handing over of the possession. The Allottee agrees to pay to the Promoter, interest as specified in the Rule, on all the delayed payment which become due and payable by the Allottee to the Promoter under the terms of this Agreement from the date the said amount is payable by the allottee(s) to the Promoter. 4.3Without prejudice to the right of Promoters to charge interest in terms of sub clause 4.1 above, on the Purchasers committing default in payment on due date of any amount due and payable by the Purchasers to the Promoters under this Agreement (including his/her proportionate share of taxes levied by concerned local authority and other outgoings) and on the Purchasers committing three defaults of payment of installments, the Promoters shall at his own option, may terminate this Agreement. Provided that, Promoters shall give notice of fifteen days in writing to the Purchasers, by Registered Post AD at the address provided by the Purchasers and mail at the e-mail address provided by the Purchasers, of his intention to terminate this Agreement and of the specific breach or breaches of terms and 8 conditions in respect of which it is intended to terminate the Agreement. If the Purchasers fails to rectify the breach or breaches mentioned by the Promoters within the period of notice then at the end of such notice period, Promoters shall be entitled to terminate this Agreement. Provided further that upon termination of this Agreement as aforesaid, the Promoters shall refund the amount till then received from the Purchasers without any interest thereon within a period of 30 days of the termination, the instalments of the sale consideration of the apartment which may till hen have been paid by the allottee to the promoter. 5 The fixtures and fittings with regard to the flooring and sanitary fittings and amenities like one or more lifts with particular brand, or price range (if unbranded) to be provided by the Promoter in the said building and the Apartment as are set out in Annexure 'E', annexed hereto. 6 POSSESSION - The Promoter shall give possession of the Apartment to the Allottee on or before 31-12-2019. If the Promoter fails or neglects to give possession of the Apartment to the Allottee on account of reasons beyond his control and of his agents by the aforesaid date then the Promoter shall be liable on demand to refund to the Allottee the amounts already received by him in respect of the Apartment with interest at the same rate as may mentioned in the clause 4.1 herein above from the date the Promoter received the sum till the date the amounts and interest thereon is repaid. Provided that the Promoters shall be entitled to reasonable extension of time for giving delivery of the said premises on the aforesaid date, if the completion of the said project or building/wing in which the said premises is to be situated is delayed on account of – i. Non-availability of steel, cement, other building material, water or electric supply. ii. War, Civil Commotion or act of God. iii. Any notice, order, rule, notification of the Government and / or other public or Competent Authority or any Decree/Order of any Court/ Tribunal/ Authority. iv. Any Prohibitory or Injunction Order from any Court of Law. v. Pendency of any litigation and any order therein. vi. Delay or default in payment of any installment or dues by the Flat Purchaser. vii. Delay by Local Authority in issuing or granting necessary Completion Certificate or Occupation Certificate. viii. Any other circumstances beyond the control of the Promoters or force majeure. ix. Changes in any rules, regulations, bye-laws of various statutory bodies and authorities from time to time affecting the development and the project. x. Delay in grant of any NOC/ permission/ license/ connection installment of any services such as elevators, electricity and water connections and meters to the project/ flat/ premises/road etc. or completion certificate from any appropriate authority. xi. Extension of time for giving possession as may be permitted by the Regulatory authority under Real Estate (Regulation and Development) Act, 2016 for reason where actual work of said project/building could not be carried by the promoters as per sanctioned plan due to specific stay or injunction orders relating to the said project from any Court of law, or Tribunal, competent authority, statutory authority, high power committee etc. or due to such circumstances as may be decided by the Authority. 9 If, however, the completion of the Project is delayed due to the Force Majeure conditions then the Purchasers agrees that the Promoters shall be entitled to the extension of time for delivery of possession of the said Premises, provided that such Force Majeure conditions are not of a nature which make it impossible for the contract to be implemented. The Purchasers agrees and confirms that, in the event it becomes impossible for the Promoters to implement the project due to Force Majeure conditions, then this allotment shall stand terminated and the Promoters shall refund to the Purchasers the entire amount received by the Promoters from the allotment within 30 days from that date. After any refund of the money paid by the Purchasers, Purchasers agrees that he/ she shall not have any rights, claims etc. against the Promoters and that the Promoters shall be released and discharged from all its obligations and liabilities under this Agreement. 7.1 Procedure for taking possession - The Promoter, upon obtaining the occupancy certificate from the competent authority and the payment made by the Allottee as per the agreement shall offer in writing the possession of the Apartment, to the Allottee in terms of this Agreement to be taken within 15 days from the date of issue of such notice and the Promoter shall give possession of the Apartment to the Allottee. The Promoter agrees and undertakes to indemnify the Allottee in case of failure of fulfilment of any of the provisions, formalities, documentation on part of the Promoter. The Allottee agree(s) to pay the maintenance charges as determined by the Promoter or association of allottees, as the case may be. The Promoter on its behalf shall offer the possession to the Allottee in writing within 7 days of receiving the occupancy certificate of the Project. 7.2 The Allottee shall take possession of the Apartment within 15 days of the written notice from the promoter to the Allottee intimating that the said Apartments are ready for use and occupancy: 7.3 Failure of Allottee to take Possession of Apartment : Upon receiving a written intimation from the Promoter as per clause 7.1, the Allottee shall take possession of the Apartment from the Promoter by executing necessary indemnities, undertakings and such other documentation as prescribed in this Agreement, and the Promoter shall give possession of the Apartment to the allottee. In case the Allottee fails to take possession within the time provided in clause 7.1 such Allottee shall continue to be liable to pay maintenance charges as applicable. 7.4 If within a period of five years from the date of handing over the Apartment to the Allottee, the Allottee brings to the notice of the Promoter any structural defect in the Apartment or the building in which the Apartment are situated or any defects on account of workmanship, quality or provision of service, then, wherever possible such defects shall be rectified by the Promoter at his own cost and in case it is not possible to rectify such defects, then the Allottee shall be entitled to receive from the Promoter, compensation for such defect in the manner as provided under the Act. Provided however, that the allottee shall not carry out any alterations of the whatsoever nature in the said apartment of phase/ wing and in specific the structure of the said unit of the said building which shall include but not limit to columns, beams, etc. or in the fittings therein, in particular it is hereby agreed that the allottee shall not make any alterations in any of the fittings, pipes, water supply connections or any erection or alteration in the bathroom, toilet and kitchen which may result in seepage of the water. If any of the works are carried out without the written 10 consent of the promoter the defect liability automatically shall become void. The word defect here means only the manufacturing. That it shall be the responsibility of the allottee to maintain his unit in a proper manner and take all due care needed including but not limiting to the joints in the tiles in his flat are regularly filled with white cement /epoxy to prevent water seepage. That the allottee has been made aware and that the allottee expressly agrees that the regular wear and tear of the unit includes minor hairline cracks on the external and internal walls excluding the RCC structure which happens due to variations in temperature of more than 20*C and which do not amount to structural defects and hence cannot be attributed to either bad workmanship or structural defect. It is expressly agreed that before any liability of defect is claimed by or on behalf of the allottee, it shall be necessary to appoint an expert who shall be a nominated surveyor who shall survey and assess the same and shall then submit a report to state the defects in materials used, in the structures built of the unit and in the workmanship executed keeping in mind the aforesaid agreed clauses of this agreement. 8 The Allottee shall use the Apartment or any part thereof or permit the same to be used only for purpose of residence. He shall use the garage or parking space only for purpose of keeping or parking vehicle. 9 The Allottee along with other allottee(s)s of Apartments in the building shall join in forming and registering the Association to be known by such name as the Promoter may decide and for this purpose also from time to time sign and execute the application for registration and/or membership and the other papers and documents necessary for the formation and registration of the Association of Apartment Owners and for becoming a member, including the bye-laws of the proposed association and duly fill in, sign and return to the Promoter within seven days of the same being forwarded by the Promoter to the Allottee, so as to enable the Promoter to register the common organisation of Allottee. No objection shall be taken by the Allottee if any, changes or modifications are made in the draft bye-laws, or the Memorandum and/or Articles of Association, as may be required by the Registrar of Co-operative Societies as the case may be, or any other Competent Authority. 9.1 The Promoter shall, within three months of registration of the Association or within three months from the completion certificate from Nashik Municipal Corporation, whichever is later cause to be transferred to the association all the right, title and the interest of the Vendor/Promoter and/or the owners in the said structure of the Building or wing in which the said Apartment is situated. 9.2 The Promoter shall, within three months of registration of the association of apartment owners or within three months from the completion certificate from Nashik Municipal Corporation whichever is later cause to be transferred to the association all the right, title and the interest of the Vendor/ Promoter and/or the owners in the project land on which the building with multiple wings or buildings are constructed. 11 9.3 Within 15 days after notice in writing is given by the Promoter to the Allottee that the Apartment is ready for use and occupancy, the Allottee shall be liable to bear and pay the proportionate share (i.e. in proportion to the carpet area of the Apartment) of outgoings in respect of the project land and Building/s namely local taxes, betterment charges or such other levies by the concerned local authority and/or Government water charges, insurance, common lights, repairs and salaries of clerks bill collectors, chowkidars, sweepers and all other expenses necessary and incidental to the management and maintenance of the project land and building/s. Until the Society or Limited Company is formed and the said structure of the building/s or wings is transferred to it, the Allottee shall pay to the Promoter such proportionate share of outgoings as may be determined. The Allottee further agrees that till the Allottee's share is so determined the Allottee shall pay to the Promoter provisional monthly contribution of Rs. 1000/- per month towards the outgoings. The amounts so paid by the Allottee to the Promoter shall not carry any interest and remain with the Promoter until a conveyance/assignment of lease of the structure of the building or wing is executed in favour of the association as aforesaid. On such conveyance/assignment of lease being executed for the structure of the building or wing the aforesaid deposits (less deduction provided for in this Agreement) shall be paid over by the Promoter to the Society or the Limited Company, as the case may be. 10. The above amount of consideration does not include the following expenses which the Allottee shall on or before delivery of possession of the said premises keep deposited with the Promoter, the following amounts:- (i) Rs. NIL for share money, application entrance fee of the association. (ii) Rs. 10,000/- for formation and registration of the association. (iii) Rs. NIL for proportionate share of taxes and other charges /levies in respect of the association. (iv) Rs. 30,000/- Towards the proportionate expenses of installation charges for common water meter, and electric meter, individual electric meter, connection, proportionate amount towards the MSEB ORC charges and deposit and installation charges, etc. and common water meter connection charges. 11.The Allottee shall pay to the Promoter a sum of Rs. 10,000/- for meeting all legal costs, charges and expenses, including professional costs of the Attorney-at-Law/Advocates of the Promoter in connection with formation of the said Society, or Limited Company, or Apex Body or Federation and for preparing its rules, regulations and bye-laws and the cost of preparing and engrossing the conveyance or assignment of lease. 12.At the time of registration of conveyance of the structure of the building or wing of the building, the Allottee shall pay to the Promoter, the Allottees' share of stamp duty and registration 12 charges payable, by the said association on such conveyance or lease or any document or instrument of transfer in respect of the structure of the said Building /wing of the building. At the time of registration of conveyance or Lease of the project land, the Allottee shall pay to the Promoter, the Allottees' share of stamp duty and registration charges payable, by the said association on such conveyance or any document or instrument of transfer in respect of the structure of the said land to be executed in favour of the Apex Body or Federation. 13. REPRESENTATIONS AND WARRANTIES OF THE PROMOTER :- The Promoter hereby represents and warrants to the Allottee as follows: i. The Promoter has clear and marketable title with respect to the project land; the requisite rights to carry out development upon the said Land and absolute, actual, physical and legal possession of the said land for project; ii. The Promoter has lawful rights and requisite approvals from the competent Authorities to carry out development of the Project and shall obtain requisite approvals from time to time to complete the development of the project; iii. There are no encumbrances upon the project land or the Project except those disclosed in the title report; iv. There are no litigations pending before any Court of law with respect to the project land or Project except those disclosed in the title report; v. All approvals, licenses and permits issued by the competent authorities with respect to the Project, project land and said building/wing are valid and subsisting and have been obtained by following due process of law. Further, all approvals, licenses and permits to be issued by the competent authorities with respect to the Project, project land and said building/wing shall be obtained by following due process of law and the Promoter has been and shall, at all times, remain to be in compliance with all applicable laws in relation to the Project, project land, Building/wing and common areas; vi. The Promoter has the right to enter into this Agreement and has not committed or omitted to perform any act or thing, whereby the right, title and interest of the Allottee created herein, may prejudicially be affected; vii. The Promoter has not entered into any agreement for sale and/or development agreement or any other agreement / arrangement with any person or party with respect to the project land, including the Project and the said [Apartment/Plot] which will, in any manner, affect the rights of Allottee under this Agreement; viii. The Promoter confirms that the Promoter is not restricted in any manner whatsoever from selling the said [Apartment / Plot] to the Allottee in the manner contemplated in this Agreement; ix. At the time of execution of the conveyance deed of the structure to the association of allottees the Promoter shall handover lawful, vacant, peaceful, physical possession of the common areas of the Structure to the Association of the Allottees; 13 x. The Schedule property is not the subject matter of any HUF and that no part thereof is owned by any minor and or no minor has any right, title and claim over the Schedule Property. xi. The Promoter has duly paid and shall continue to pay and discharge undisputed governmental dues, rates, charges and taxes and other monies, levies, impositions, premiums, damages and/or penalties and other outgoings, whatsoever, payable with respect to the said project to the competent Authorities; xii. No notice from the Government or any other local body or authority or any legislative enactment, government ordinance, order, notification (including any notice for acquisition or requisition of the said property) has been received or served upon the Promoter in respect of the project land and/or the Project except those disclosed in the title report. 13.1 It is further agreed by and between the parties that the Promoters shall not be liable to pay the adhoc maintenance charges for the UNSOLD premises till final conveyance of the said UNSOLD premises. It is further agreed and understood between the Parties that after the formation of the Organization, the Promoters shall be absolutely entitled to hold and shall have absolute authority and control as regards the unsold premises, units, etc. and all the amenities and facilities in the said Project. The Promoters shall have full right, absolute power and authority, and shall be unconditionally entitled to deal with and to sell, let or otherwise dispose of the unsold flats along with the other amenities in any manner and for such consideration, and on such terms and conditions as it may in its sole and absolute discretion deem fit and proper, to any person or party of its choice without payment of any premium or transfer fees or charges, donation or compensation or costs in any form. Neither the Purchasers herein, nor the Organization shall object to or dispute to any such transaction dealing with the unsold units. The promoters upon intimating to the Organization the name or names of the Purchasers or acquirer/s of such unsold flats and amenities, the Organization shall forthwith accept and admit such Purchasers and acquirer/s as the Flat Purchasers and shareholder/s and/or members of the Organization, and shall forthwith issue share certificate/s and other necessary documents in their favour, without raising any dispute or objection to the same, and without charging/ recovering from such Purchasers and acquirer/s as any premium, fees, donation or any other amount of whatsoever nature in respect thereof. 14. The Allottee/s or himself/themselves with intention to bring all persons into whosoever hands the Apartment may come, hereby covenants with the Promoter as follows :- i. To maintain the Apartment at the Allottee's own cost in good and tenantable repair and condition from the date that of possession of the Apartment is taken and shall not do or suffer to be done anything in or to the building in which the Apartment is situated which may be against the rules, regulations or bye-laws or change/alter or make addition in or to the building in which the Apartment is situated and the Apartment itself or any part thereof without the consent of the local authorities, if required. ii. Not to store in the Apartment any goods which are of hazardous, combustible or dangerous nature or are so heavy as to damage the construction or structure of the building in which the Apartment is situated or storing of which goods is objected to by the concerned local or other authority and shall take care while carrying heavy 14 packages which may damage or likely to damage the staircases, common passages or any other structure of the building in which the Apartment is situated, including entrances of the building in which the Apartment is situated and in case any damage is caused to the building in which the Apartment is situated or the Apartment on account of negligence or default of the Allottee in this behalf, the Allottee shall be liable for the consequences of the breach. iii. To carry out at his own cost all internal repairs to the said Apartment and maintain the Apartment in the same condition, state and order in which it was delivered by the Promoter to the Allottee and shall not do or suffer to be done anything in or to the building in which the Apartment is situated or the Apartment which may be contrary to the rules and regulations and bye-laws of the concerned local authority or other public authority. In the event of the Allottee committing any act in contravention of the above provision, the Allottee shall be responsible and liable for the consequences thereof to the concerned local authority and/or other public authority. iv. Not to demolish or cause to be demolished the Apartment or any part thereof, nor at any time make or cause to be made any addition or alteration of whatever nature in or to the Apartment or any part thereof, nor any alteration in the elevation and outside colour scheme of the building in which the Apartment is situated and shall keep the portion, sewers, drains and pipes in the Apartment and the appurtenances thereto in good tenantable repair and condition, and in particular, so as to support shelter and protect the other parts of the building in which the Apartment is situated and shall not chisel or in any other manner cause damage to columns, beams, walls, slabs or RCC, Pardis or other structural members in the Apartment without the prior written permission of the Promoter and/or the Society or the Limited Company. v. Not to do or permit to be done any act or thing which may render void or voidable any insurance of the project land and the building in which the Apartment is situated or any part thereof or whereby any increased premium shall become payable in respect of the insurance. vi. Not to throw dirt, rubbish, rags, garbage or other refuse or permit the same to be thrown from the said Apartment in the compound or any portion of the project land and the building in which the Apartment is situated. vii. Pay to the Promoter within fifteen days of demand by the Promoter, his share of security deposit demanded by the concerned local authority or Government or giving water, electricity or any other service connection to the building in which the Apartment is situated. viii. To bear and pay increase in local taxes, water charges, insurance and such other levies, if any, which are 15 imposed by the concerned local authority and/or Government and/or other public authority, on account of change of user of the Apartment by the Allottee for any purposes other than for purpose for which it is sold. ix. The Allottee shall not let, sub-let, transfer, assign or part with interest or benefit factor of this Agreement or part with the possession of the Apartment until all the dues payable by the Allottee to the Promoter under this Agreement are fully paid up. x. The Allottee shall observe and perform all the rules and regulations which the Society or the Limited Company or Apex Body or Federation may adopt at its inception and the additions, alterations or amendments thereof that may be made from time to time for protection and maintenance of the said building and the Apartments therein and for the observance and performance of the Building Rules, Regulations and Bye-laws for the time being of the concerned local authority and of Government and other public bodies. The Allottee shall also observe and perform all the stipulations and conditions laid down by the Society/Limited Company/Apex Body/Federation regarding the occupancy and use of the Apartment in the Building and shall pay and contribute regularly and punctually towards the taxes, expenses or other out-goings in accordance with the terms of this Agreement. xi. Till a conveyance of the structure of the building in which Apartment is situated is executed in favour of Society /Limited Society, the Allottee shall permit the Promoter and their surveyors and agents, with or without workmen and others, at all reasonable times, to enter into and upon the said buildings or any part thereof to view and examine the state and condition thereof. xii. Till a conveyance of the project land on which the building in which Apartment is situated is executed in favour of Apex Body or Federation, the Allottee shall permit the Promoter and their surveyors and agents, with or without workmen and others, at all reasonable times, to enter into and upon the project land or any part thereof to view and examine the state and condition thereof. xiii. Not to make any changes in elevatgion such as enclosures in terraces, balconies, dry balconies, addition of grills, etc. and installations of dish antenns without the permission of the vendor. xiv. Not to change the windows, window grills, railings of the said flat. 15. The Promoter shall maintain a separate account in respect of sums received by the Promoter from the Allottee as advance or deposit, sums received on account of the share capital for the promotion of the Co-operative Society or association or Company or towards the out goings, legal charges and shall utilize the amounts only for the purposes for which they have been received. 16 16. Nothing contained in this Agreement is intended to be nor shall be construed as a grant, demise or assignment in law, of the said Apartments or of the said Plot and Building or any part thereof. The Allottee shall have no claim save and except in respect of the Apartment hereby agreed to be sold to him and all open spaces, parking spaces, lobbies, staircases, terraces recreation spaces, will remain the property of the Promoter until the said structure of the building is transferred to the Society/Limited Company or other body and until the project land is transferred to the Apex Body /Federation as hereinbefore mentioned. 17. PROMOTER SHALL NOT MORTGAGE OR CREATE A CHARGE After the Promoter executes this Agreement he shall not mortgage or create a charge on the *[Apartment/] and if any such mortgage or charge is made or created then notwithstanding anything contained in any other law for the time being in force, such mortgage or charge shall not affect the right and interest of the Allottee who has taken or agreed to take such [Apartment/plot]. 18. BINDING EFFECT Forwarding this Agreement to the Allottee by the Promoter does not create a binding obligation on the part of the Promoter or the Allottee until, firstly, the Allottee signs and delivers this Agreement with all the schedules along with the payments due as stipulated in the Payment Plan within 30 (thirty) days from the date of receipt by the Allottee and secondly, appears for registration of the same before the concerned Sub-Registrar as and when intimated by the Promoter. If the Allottee(s) fails to execute and deliver to the Promoter this Agreement within 30 (thirty) days from the date of its receipt by the Allottee and/or appear before the Sub-Registrar for its registration as and when intimated by the Promoter, then the Promoter shall serve a notice to the Allottee for rectifying the default, which if not rectified within 15 (fifteen) days from the date of its receipt by the Allottee, application of the Allottee shall be treated as cancelled and all sums deposited by the Allottee in connection therewith including the booking amount shall be returned to the Allottee without any interest or compensation whatsoever. 19. ENTIRE AGREEMENT This Agreement, along with its schedules and annexures, constitutes the entire Agreement between the Parties with respect to the subject matter hereof and supersedes any and all understandings, any other agreements, allotment letter, correspondences, arrangements whether written or oral, if any, between the Parties in regard to the said apartment/plot/building, as the case may be. 20. RIGHT TO AMEND This Agreement may only be amended through written consent of the Parties. 21. PROVISIONS OF THIS AGREEMENT APPLICABLE TO ALLOTTEE /SUBSEQUENT ALLOTTEES 17 It is clearly understood and so agreed by and between the Parties hereto that all the provisions contained herein and the obligations arising hereunder in respect of the Project shall equally be applicable to and enforceable against any subsequent Allottees of the [Apartment/Plot], in case of a transfer, as the said obligations go along with the [Apartment/Plot] for all intents and purposes. 22. SEVERABILITY If any provision of this Agreement shall be determined to be void or unenforceable under the Act or the Rules and Regulations made thereunder or under other applicable laws, such provisions of the Agreement shall be deemed amended or deleted in so far as reasonably inconsistent with the purpose of this Agreement and to the extent necessary to conform to Act or the Rules and Regulations made thereunder or the applicable law, as the case may be, and the remaining provisions of this Agreement shall remain valid and enforceable as applicable at the time of execution of this Agreement. 23. METHOD OF CALCULATION OF PROPORTIONATE SHARE WHEREVER REFERRED TO IN THE AGREEMENT Wherever in this Agreement it is stipulated that the Allottee has to make any payment, in common with other Allottee(s) in Project, the same shall be in proportion to the carpet area of the Apartment] to the total carpet area of all the Apartments in the Project. 24. FURTHER ASSURANCES Both Parties agree that they shall execute, acknowledge and deliver to the other such instruments and take such other actions, in additions to the instruments and actions specifically provided for herein, as may be reasonably required in order to effectuate the provisions of this Agreement or of any transaction contemplated herein or to confirm or perfect any right to be created or transferred hereunder or pursuant to any such transaction. 25. PLACE OF EXECUTION The execution of this Agreement shall be complete only upon its execution by the Promoter through its authorized signatory at the Promoter’s Office, or at some other place, which may be mutually agreed between the Promoter and the Allottee, in Nashik after the Agreement is duly exeuted by the Allottee and the Promoter or simultaneously with the execution the said Agreement shall be registered at the office of Sub-Registrar. Hence this Agreement shall be deemed to have been executed at NASHIK. 26. The Allottee and/or Promoter shall present this Agreement as well as the conveyance/assignment of lease at the proper registration office of registration within the time limit prescribed by the Registration Act and the Promoter will attend such office and admit execution thereof. 18 27. That all notices to be served on the Allottee and the Promoter as contemplated by this Agreement shall be deemed to have been duly served if sent to the Allottee or the Promoter by Registered Post A.D and notified Email ID/Under Certificate of Posting at their respective addresses specified below: PURCHASERS NAME AND ADDRESS MR. __________________________________ R/o. __________________________________ Notified Email ID : _______________________ PROMOTERS NAME- MRS. MANISHA VISHNU RANE, Age 46 Years, Occupation Business, R/o. Flat No. 2, Govind Park, Untwadi, Nashik 422 009, PAN AEHPR 7441 D, Notified Email Id - vishnurane@gmail.com It shall be the duty of the Allottee and the promoter to inform each other of any change in address subsequent to the execution of this Agreement in the above address by Registered Post failing which all communications and letters posted at the above address shall be deemed to have been received by the promoter or the Allottee, as the case may be. 28. JOINT ALLOTTEES That in case there are Joint Allottees all communications shall be sent by the Promoter to the Allottee whose name appears first and at the address given by him/her which shall for all intents and purposes to consider as properly served on all the Allottees. 29. STAMP DUTY AND REGISTRATION :- The charges towards stamp duty and Registration of this Agreement shall be borne by the allottee. 30. DISPUTE RESOLUTION :- Any dispute between parties shall be settled amicably. In case of failure to settled the dispute amicably, which shall be referred to the RERA Authority as per the provisions of the Real Estate (Regulation and Development) Act, 2016, Rules and Regulations, thereunder. 31. GOVERNING LAW That the rights and obligations of the parties under or arising out of this Agreement shall be construed and enforced in accordance with the laws of India for the time being in force and the Nashik courts will have the jurisdiction for this Agreement 32. The Promoter has informed the allottee and the allottee is aware that the purchase of the said apartment shall be subject to all the following conditions:- a] The access to the individual flat shall be as per the sanctioned plan and/or revised plan from time to time. b] Construction of a loft and other civil changes done internally shall be at the risk and cost of the purchaser, the purchaser shall not damage the basic RCC structure. 19 c] The installation of any grills or any doors shall only be as per the form prescribed by the Vendor's Architect. d] The car parking area shall not be enclosed under any circumstances. FIRST SCHEDULE OF THE SAID PROPERTY All that piece and parcel of land bearing S. No. 761/6/4/4 to 8/13 bearing Plot No. 13+14 total admeasuring 420-00 Sq. Mtrs. Situated at Nashik Taluka and District Nashik, within registration and sub Registration District of Nashik within Nashik Municipal Corporation Bounded as follows: East : By Open space West : By 6 Mtrs. Colony Road South : By Plot No. 11 North : By 6 Mtrs. wide Road SECOND SCHEDULE OF OWNERSHIP THE PROPERTY AGREED TO BE TRANSFERED ALL THAT PIECE and parcel of constructed flats constructed on the property as mentioned in the first schedule bearing Flat No. ____ on __________ Floor admeasuring ___________ Sq. Mtrs. Carpet area and usable area of Balconies + utility+ C/B /Terrace area of _________ Sq. mtrs. and Parking admeasuring _______ Sq. Mtrs. In SRI GURUMANGAL APARTMENT bounded as follows: On or towards East : By On or towards West : By On or towards South : By On or towards North : By SCHEDULE ‘B’ - FLOOR PLAN OF THE APARTMENT ANNEXURE A TITLE CERTIFICATE ANNEXURE B – 7/12 EXTRACT ANNEXURE C LAYOUT ANNEXURE D BUILDING PLAN ANNEXURE - E AMENITIES TO BE PROVIDED IN THE FLAT  Structure shall be of RCC Frame type.  Brick Masonary : External 6" brick masonary and internal 4" thick brick masonary work.  Plastering : External sand plastering work and internal smooth neeru finished plaster work.  Flooring : All flooring will be done in 12” x 12” plain Ceramic Tiles.  For bath :- Tandoor stone flooring with 6' high white glazed tiles dado.  For W.C. :- White glazed tiles flooring with 3' high white glazed tiles dado.  Electrification :- Electrification will be in casing - capping Patti fittings with necessary points and power points as per standard.  Doors and windows :- Door - All door frames will be in pure Malesiya Teakwood or marble and Doors Shutters will be water-proof flush door with oil paints in two coat.  W. C. and Bath :- Cement frame. 20  Windows :- Windows will be in three track aluminum sliding windows in hall and bed & two track aluminum sliding windows in kitchen.  Kitchen Platform :- 8’ Kitchen platform will be economy range granite Stone with stainless steel sink, etc.  Colouring :- External water proof cement paint in pleasant shade and internal white wash.  Common staircase will be provided with tandoor stone on entire steps and mid landing.  All sanitary and plumbing fittings of economy quality.  One 12”x12” wash basin will be provided in attached toilet.  Glazed tiles above kitchen otta upto lintel level.  Allotted Parking for every individual flat. IN WITNESS WHEREOF THE PARTIES HERETO HAVE SIGNED HEREUNTO ON THIS DAY, DATE AND YEAR FIRST MENTIONED HEREINABOVE. SIGNED SEALED AND DELIVERED ] BY THE WITHIN NAMED ] MRS. MANISHA VISHNU RANE ] ----------------------- [VENDOR/PROMOTER] ] ] ] SIGNED SEALED AND DELIVERED ] BY THE WITHIN NAMED ] MR. _____________________ ] [PURCHASER/ALLOTTEE] ] Witnesses 1. ----------------------------------------- 2. ----------------------------------------- BUILDER-VISHNU RANE - SRI-GURUMANGAL-draft