Annexure ‘A’ Model Form of Agreement to be entered into between Promoter and Allottee(s) (See rule 10(1)) EXPLANATORY NOTE This is a model form of Agreement, which may be modified and adapted in each case having regard to the facts and circumstances of respective case but in any event, matter and substance mentioned in those clauses, which are in accordance with the statute and mandatory according to the provisions of the Act shall be retained in each and every Agreement executed between the Promoter and Allottee. Any clause in this agreement found contrary to or inconsistent with any provisions of the Act, Rules and Regulations would be void ab-initio. Model Form of Agreement This Agreement made at...........this........day of.......... in the year Two Thousand and ______________ between - M/s MAHARANA & BOSE ASSOCIATES, A Partnership Firm, having its Office at 1st Floor, ‘Shivhare Bhawan’, Koshtipura, sitabuldi, Nagpur (Income Tax PAN – AAIFM8077H) (Date of Incorporation - ______________) acting through its Partners: (1) MR. VILAS SAHEBRAO DESHMUKH, Aged 64 Years (Date of Birth 11-08- 1960), Occupation – Business, (Income Tax PAN – ABKPD3417H) (Aadhar No. 9871 7784 5831) (Mobile No. 9823096758) (Email Id - vilasdesh11@gmail.com) Resident of Plot No. 122, Gawande Layout, Near Telecom Nagar, Ring Road, Nagpur Pin Code No. 440022, Tahsil & District – NAGPUR and (2) MR. RAJENDRANATH MANINDRANATH BOSE, Aged 57 years (Date of Birth 08-04-1967), Occupation – Business, (Income Tax PAN – ABAPB1520B) (Aadhar No. ) (Mobile No. ) Resident of 285, Dhaampeth Extension, Nagpur Pin Code No. 440010, Tahsil & District – NAGPUR, hereinafter referred to as "the Vendor/Promoter/Developer” of the One Part and MR. , aged about years, Occupation – __________, (Income Tax PAN – ) (Aadhar No. ), (Mobile No.: ________________________), (Email Id – ) Resident of , hereinafter referred to as " the Allottee" of the Other Part. WHEREAS, by an Agreement/Conveyance dated ........................... day of ...................20....... and executed between ………………………………. of the One Part (hereinafter referred to as " the Vendor") and the Promoter of the Other Part, the Vendor agreed with the Promoter for the absolute sale to the Promoter/sold absolutely to the Promoter an immovable property being piece or parcel of freehold land bearing Survey No. ______________ lying and being survey no. at ................................. in the Registration Sub-District of ............................ admeasuring sq. mts. or thereabouts more particularly described in the First Schedule hereunder written (hereinafter referred to as “the project land”). Page 1 of 24 OR WHEREAS by and under a Lease / an Agreement for Lease dated the ………… day of .................20....... made between of the One Part (hereinafter referred to as " the Lessor") and the Promoter of the Other Part, the Lessor agreed to grant unto the Promoter a lease in perpetuity/for a term of ....... years in respect of a piece or parcel of leasehold land bearing situate at ............., admeasuring ________ sq. mtrs. or thereabouts more particularly described in the First Schedule hereunder written (hereinafter referred to as " the project land") at a rent of Rs. .......... per annum/month and on the terms and conditions contained in the said Lease Deed/Agreement for Lease. AND WHEREAS the lease Deed/Agreement for Lease, is with the benefit and right to construct any new building/s if so permitted by the concerned local authority. OR WHEREAS by an Agreement dated __________ day of 20. /Power of Attorney dated _________ executed between Shri (hereinafter referred to as "the Original Owner”) of the One Part and the Promoter of the Other Part (hereinafter referred to as "the Development Agreement"), the Original Owner granted to the Promoter development rights to the piece or parcel of freehold land lying and being at ................ in the Registration Sub-District of admeasuring _____________ sq. mts., or thereabouts more particularly described in the First Schedule therein as well as in the First Schedule hereunder written (hereinafter referred to as "the project land') and to construct thereon building/s in accordance with the terms and conditions contained in the Development Agreement/Power of Attorney; WHEREAS the Vendor/Promoter/Developer is the absolute owner of an immovable property comprising ALL THAT Piece and Parcel of land bearing Amalgamated Plot No. 16- 17, containing by admeasurements 2957.00 Sq. Mtrs. (i.e. 31829.148 Sq. Ft.) being a portion of the entire land bearing Khasra No. 35/5 of Mouza – GOREWADA, Patwari Halka No. 8-A TOGETHERWITH a Multistoreyed Buildings proposed to be constructed thereon and to be known and styled as “WING-A-SATPUDA and WING-B-SAHYADRI APARTMENTS”, bearing City Survey No. 37 and Sheet No. 32/32, situated at Grewada, Nagpur, within the limits of the Nagpur Municipal Corporation Ward No. 61 in Tahsil and District – NAGPUR and more particularly described in the First Schedule hereunder written (hereinafter referred to as “the project land”). (Give Complete Recital of the Title of the Promoter to the plot on which promoter proposes to construct and sale the Apartment) WHEREAS ALL THAT Piece and Parcel of land bearing Khasra No. 35/5, having an area of 1.97 Hectare R., held in the Bhogwatdar Class-II Rights of Mouza – GOREWADA, Patwari Halka No. 8-A, and including all other easementary rights appurtenant belonging thereto, bearing City Survey No. 37 and Sheet No. 32/32, situate at Gorewada, Nagpur, within the limits of the Nagpur Municipal Corporation in Tahsil and District – NAGPUR, Originally belonged to Mr. Jaiamji Raut as a recorded Owner thereof being his separate property and the same is mutated in his name in all relevant records; AND Page 2 of 24 WHEREAS the aforesaid Mr. Jairamji Raut left for heavenly abode on 03.12.199 and consequent upon his demise/death, his aforesaid property devolved upon his widow namely Smt. Sarubai Jaiamji Raut, four Sons namely (1) Mr. Laxman Jairamji Raut, (2) Mr. Umraoji Jairamji Raut, (3) Mr. Yogiraj Jairamji Raut & (4) Mr. Kishor Jairamji Raut and only married daughter namely Mrs. Jyoti Subhasrao Mahalle jointly by way of intestate succession being the only heirs of the deceased; AND WHEREAS out of the aforesaid legal heirs namely Smt. Sarubai Jaiamji Raut also left for heavenly abode on 30.01.2007 and consequent upon her demise/death, her undivided share in the aforesaid property devolved upon her four Sons namely (1) Mr. Laxman Jairamji Raut,(2) Mr. Umraoji Jairamji Raut, (3) Mr. Yogiraj Jairamji Raut & (4) Mr. Kishor Jairamji Raut and only married daughter namely Mrs. Jyoti Subhasrao Mahalle jointly by way of intestate succession being the only heirs of the deceased; AND WHEREAS the aforesaid Mrs. Jyoti Subhasrao Mahalle lateron relinquished/released all her rights, titles, share and interest in the aforesaid property in favour of remaining Co- owners namely (1) Mr. Laxman Jairamji Raut, (2) Mr. Umraoji Jairamji Raut, (3) Mr. Yogiraj Jairamji Raut & (4) Mr. Kishor Jairamji Raut, by executing a Relinquishment/Release Deed Dated 04.01.2011, which is duly registered in the Office of the Sub Registrar, Nagpur in Book No. 1 at Registered Sr. No. 2/2011 on 04.01.2011; AND WHEREAS the aforesaid (1) Mr. Laxman Jairamji Raut, (2) Mr. Umraoji Jairamji Raut, (3) Mr. Yogiraj Jairamji Raut & (4) Mr. Kishor Jairamji Raut jointly lateron transferred/sold their aforesaid property bearing Khasra No. 35/5, having an area of 1.97 Hectare R., by way of Sale to M/s Maharana & Bose Associates acting through its Partners (1) Mr. Vilas Sahebrao Deshmukh and (2) Mr. Rajendranath Manindranath Bose, by a Sale Deed Dated 15.02.2013, which is duly registered in the Office of the Sub Registrar, Nagpur-6 in Book No. 1 at Registered Sr. No. 1235/2013 on 16.02.2013. As a result, therefore the aforesaid M/s Maharana & Bose Associates acting through its Partners (1) Mr. Vilas Sahebrao Deshmukh and (2) Mr. Rajendranath Manindranath Bose has now become an exclusive, absolute and full Owner of the aforesaid property with heritable and transferable rights therein; AND WHEREAS the said M/s Maharana & Bose Associates acting through its Partners (1) Mr. Vilas Sahebrao Deshmukh and (2) Mr. Rajendranath Manindranath Bose lateron decided to develop the said land bearing Khasra No. 35/5 into a RESIDENTIAL LAYOUT by carving out various Plots of different sizes therein; AND WHEREAS, out of the aforesaid layout, the Plot No. 16 is converted for Non- Agricultural (Residential) use by the Additional Tahsildar, Non-Agricultural Tax Assessment, Nagpur vide its Order Dated 27.02.2019 passed in Revenue Case No. 2975/N.A.P.-34/2018- 19 of Mouza – Gorewada; AND WHEREAS, in the like manner, the Plot No. 17 is converted for Non-Agricultural (Residential) use by the Additional Tahsildar, Non-Agricultural Tax Assessment, Nagpur vide its Order Dated 27.06.2018 passed in Revenue Case No. 6943/N.A.P.- 34/2017-18 of Mouza – Gorewada; AND WHEREAS, the aforesaid M/s Maharana & Bose Associates acting through its Partners (1) Mr. Vilas Sahebrao Deshmukh and (2) Mr. Rajendranath Manindranath Bose later on applied to the Nagpur Municipal Corporation, Nagpur for amalgamation of the aforesaid Plot Nos. 16 and 17 into Single Unit. Considering its request the Nagpur Municipal Corporation, Nagpur lateron amalgamated the aforesaid Plot Nos. Page 3 of 24 16 and 17 into Single Unit. And accordingly, an Amalgamation Letter to that effect is also issued by the Town Planner of Nagpur Municipal Corporation, Nagpur in favour of M/s Maharana & Bose Associates acting through its Partners (1) Mr. Vilas Sahebrao Deshmukh and (2) Mr. Rajendranath Manindranath Bose vide its Amalgamation Letter No. म.न.पा./न.र.ि◌◌व./एकञीकरण/33 Dated 28.07.2020. As per the said Amalgamation Letter Dated 28.07.2020, the Plot Numbers mentioned as 16- 17, containing by admeasurements 2957.00 Sq. Mtrs.; AND WHEREAS the aforesaid M/s Maharana & Bose Associates acting through its Partners (1) Mr. Vilas Sahebrao Deshmukh and (2) Mr. Rajendranath Manindranath Bose lateron decided to develop the said Amalgamated Plot No. 17-18 into a RESIDENTIAL ESTATE by constructing a Multistoreyed Buildings thereon consisting of various self- contained separate Apartments therein; AND WHEREAS accordingly the said M/s Maharana & Bose Associates acting through its Partners (1) Mr. Vilas Sahebrao Deshmukh and (2) Mr. Rajendranath Manindranath Bose has prepared a Plan of a Multistoreyed Buildings proposed to be constructed on the said Amalgamated Plot No. 17-18 and to be known and styled as “WING-A-SATPUDA and WING-B-SAHYADRI APARTMENTS” and the same is also duly sanctioned and approved by the Deputy Engineer, Town Planning Section, Nagpur Municipal Corporation, Nagpur, vide its Building Permit No. ADTP (Dharampeth Zone) AB-W-G-16,17/Tacking No. 202104091/164 Dated 30.04.2021; AND (Also specify (i) Any covenants affecting the said property. (ii) Any impediments attached to the said property. (iii) Number and Area occupied by Tenants and how they are proposed to be settled so as to have clear possession of the said property. (iv) Details of illegal encroachment on the said property. (v) Any permission (if any) required from any Government or Authority which affects the title to the property and details of all such required permissions obtained. (vi) Details of mortgage or lien or charge on the said property.) AND WHEREAS the Promoter is entitled and enjoined upon to construct buildings on the project land in accordance with the recitals hereinabove; AND WHEREAS the Vendor/Promoter is in possession of the project land. AND WHEREAS the Promoter has proposed to construct on the project land (here specify number of buildings and wings thereto) ………… having …………………………... (here specify number of Basements, /podiums/stilt and upper floors). AND WHEREAS the Allottee is offered an Apartment bearing number on the floor, (herein after referred to as the said “Apartment”) in the wing of the building called “WING-A-SATPUDA and WING-B-SAHYADRI APARTMENTS” (herein after referred to as the said “Building”) being constructed in the single phase of the said project, by the Promoter/Developer Page 4 of 24 AND WHEREAS the Promoter/Developer has entered into a standard Agreement with an Architect registered with the Council of Architects and such Agreement is as per the Agreement prescribed by the Council of Architects; AND WHEREAS the Promoter/Developer has registered the Project under the provisions of the Act with the Real Estate Regulatory Authority at ___________________ bearing No. _________________ authenticated copy is attached in Annexure ‘F’; AND WHEREAS the Promoter/Developer has appointed a structural Engineer for the preparation of the structural design and drawings of the buildings and the Promoter/Developer accepts the professional supervision of the Architect and the structural Engineer till the completion of the building/buildings. AND WHEREAS the Promoter/Developer has sole and exclusive right to sell the Apartments in the said building/s to be constructed by the Promoter/Developer on the project land and to enter into Agreement/s with the allottee(s)/s of the Apartments to receive the sale consideration in respect thereof; AND WHEREAS on demand from the allottee, the Promoter/Developer has given inspection to the Allottee of all the documents of title relating to the project land and the plans, designs and specifications prepared by the Promoter/Developer's Architects Messrs and of such other documents as are specified under the Real Estate (Regulation and Development) Act 2016 (hereinafter referred to as "the said Act") and the Rules and Regulations made thereunder; AND WHEREAS the authenticated copies of Certificate of Title issued by the attorney at law or advocate of the Promoter/Developer, authenticated copies of Property card or extract of Village Forms VI and VII and XII or any other relevant revenue record showing the nature of the title of the Promoter/Developer to the project land on which the Apartments are constructed or are to be constructed have been annexed hereto and marked as Annexure 'A' and 'B', respectively. AND WHEREAS the authenticated copies of the plans of the Layout as approved by the concerned Local Authority have been annexed hereto and marked as Annexure C-1. AND WHEREAS the authenticated copies of the plans of the Layout as proposed by the Promoter/Developer and according to which the construction of the buildings and open spaces are proposed to be provided for on the said project have been annexed hereto and marked as Annexure C-2, AND WHEREAS the authenticated copies of the plans and specifications of the Apartment agreed to be purchased by the Allottee, as sanctioned and approved by the local authority have been annexed and marked as Annexure D AND WHEREAS the Promoter/Developer has got some of the approvals from the concerned local authority(s) to the plans, the specifications, elevations, sections and of the said building/s and shall obtain the balance approvals from Page 5 of 24 various authorities from time to time, so as to obtain Building Completion Certificate or Occupancy Certificate of the said Building. AND WHEREAS while sanctioning the said plans concerned local authority and/or Government has laid down certain terms, conditions, stipulations and restrictions which are to be observed and performed by the Promoter/Developer while developing the project land and the said building and upon due observance and performance of which only the completion or occupancy certificate in respect of the said building/s shall be granted by the concerned local authority. AND WHEREAS the Promoter/Developer has accordingly commenced construction of the said building/s in accordance with the said proposed plans. AND WHEREAS the Allottee has applied to the Promoter/Developer for allotment of an Apartment No. on Floor in wing situated in the building “WING-A- SATPUDA and WING-B-SAHYADRI APARTMENTS” being constructed in the single phase of the said Project, AND WHEREAS the carpet area of the said Apartment is square meters and "carpet area" means the net usable floor area of an apartment, excluding the area covered by the external walls, areas under services shafts, exclusive balcony appurtenant to the said Apartment for exclusive use of the Allottee or verandah area and exclusive open terrace area appurtenant to the said Apartment for exclusive use of the Allottee, but includes the area covered by the internal partition walls of the apartment. AND WHEREAS, the Parties relying on the confirmations, representations and assurances of each other to faithfully abide by all the terms, conditions and stipulations contained in this Agreement and all applicable laws, are now willing to enter into this Agreement on the terms and conditions appearing hereinafter; AND WHEREAS, prior to the execution of these presents the Allottee has paid to the Promoter/Developer a sum of Rs. /- (Rupees ) only, being part payment of the sale consideration of the Apartment agreed to be sold by the Promoter/Developer to the Allottee as advance payment or Application Fee (the payment and receipt whereof the Promoter/Developer both hereby admit and acknowledge) and the Allottee has agreed to pay to the Promoter/Developer the balance of the sale consideration in the manner hereinafter appearing. AND WHEREAS, the Promoter/Developer has registered the Project under the provisions of the Real Estate (Regulation & Redevelopment) Act, 2016 with the Real Estate Regulatory Authority at No. ; AND WHEREAS, under section 13 of the said Act the Promoter/Developer is required to execute a written Agreement for sale of said Apartment with the Allottee, being in fact these presents and also to register said Agreement under the Registration Act, 1908. In accordance with the terms and conditions set out in this Agreement and as mutually agreed upon by and between the Parties, the Promoter/Developer hereby agrees to sell and the Allottee hereby agrees to purchase the (Apartment/Plot) and Page 6 of 24 the garage/covered parking (if applicable) NOW THEREFOR, THIS AGREEMENT WITNESSETH AND IT IS HEREBY AGREED BY AND BETWEEN THE PARTIES HERETO AS FOLLOWS: 1. The Promoter/Developer shall construct the said building/s consisting of basement and ground/ stilt, /................. podiums, and upper floors on the project land in accordance with the plans, designs and specifications as approved by the concerned local authority from time to time. Provided that the Promoter/Developer shall have to obtain prior consent in writing of the Allottee in respect of variations or modifications which may adversely affect the Apartment of the Allottee except any alteration or addition required by any Government authorities or due to change in law. 1(a) (i) The Allottee hereby agrees to purchase from the Promoter/Developer and the Promoter/Developer hereby agrees to sell to the Allottee Apartment No. having carpet area admeasuring sq. meters on floor in the building “WING-A-SATPUDA and WING-B-SAHYADRI APARTMENTS” (hereinafter referred to as "the Apartment") as shown in the Floor plan thereof hereto annexed and marked Annexures C-1 and C-2 for the consideration of Rs. ................... including Rs ............ being the proportionate price of the common areas and facilities appurtenant to the premises, the nature, extent and description of the common areas and facilities which are more particularly described in the Second Schedule annexed herewith. (the price of the Apartment including the proportionate price of the common areas and facilities and parking spaces should be shown separately). (ii) The Allottee hereby agrees to purchase from the Promoter/Developer and the Promoter/Developer hereby agrees to sell to the Allottee garage bearing Nos. situated at Basement and/or stilt and /or podium being constructed in the layout for the consideration of Rs. /- (iii) The Allottee hereby agrees to purchase from the Promoter/Developer and the Promoter/Developer hereby agrees to sell to the Allottee covered parking spaces bearing Nos. situated at Basement and/or stilt and /or podium being constructed in the layout for the consideration of Rs. /-. (iv) The Allottee hereby agrees to purchase from the Promoter and the Promoter hereby agrees to sell to the Allottee, garage/ covered Car parking space at level basement/podium/ stilt / mechanical Car Parking Unit bearing No. ____ admeasuring sq. ft. having ft. length x ft. breadth x ft. vertical clearance. (v) The Allottee has requested the Promoter for allotment of an open Car parking space and the Promoter agrees to allot the Allottee an open Car parking space without consideration bearing No. admeasuring sq. Page 7 of 24 ft. having ft. length x ft. breadth. 1(b) The total aggregate consideration amount for the apartment including garages/covered parking spaces is thus Rs. _________/- 1(c) The Allottee has paid on or before execution of this agreement a sum of Rs. (Rupees only) (not exceeding 10% of the total consideration) as advance payment or application fee and hereby agrees to pay to that Promoter the balance amount of Rs. (Rupees ) and shall be deposited in RERA Designated Collection Bank Account, ______ Bank, ____________ Branch having IFS Code _____________ situated at . In addition to the above bank account, I/we have opened in the same bank, RERA Designated Separate Bank Account and RERA Designated Transaction Bank Account having Account No. and respectively. (Note For projects where Promoter have Area Share, the three bank accounts of the project of all Promoter shall be listed. For projects where Promoter have Revenue Share the three bank accounts of all Promoter as well as the RERA Designated Master Bank Account of the Project shall be listed.) Allottee hereby agrees to pay to that Promoter the said balance amount in following manner: i. Amount of Rs. /- (Rupees ) (not exceeding 30% of the total consideration) to be paid to the Promoter/Developer after the execution of Agreement ii. Amount of Rs. /- (Rupees ) (not exceeding 45% of the total consideration) to be paid to the Promoter/Developer on completion of the Plinth of the building or wing in which the said Apartment is located. iii. Amount of Rs. /- (Rupees ) (not exceeding 70% of the total consideration) to be paid to the Promoter/Developer on completion of the slabs including podiums and stilts of the building or wing in which the said Apartment is located. iv. Amount of Rs. /- (Rupees ) (not exceeding 75% of the total consideration) to be paid to the Promoter/Developer on completion of the walls, internal plaster, floorings doors and windows of the said Apartment. v. Amount of Rs. /- (Rupees ) (not exceeding 80% of the total consideration) to be paid to the Promoter/Developer on completion of the Sanitary fittings, staircases, lift wells, lobbies upto the floor level of the said Apartment. vi. Amount of Rs. /- (Rupees ) (not exceeding 85% of the total consideration) to be paid to the Promoter/Developer on completion of the external plumbing and external plaster, elevation, terraces with waterproofing, of the building or wing in which the said Apartment is located. vii. Amount of Rs. /- (Rupees ) (not exceeding 95% of the total consideration) to be paid to the Promoter/Developer on completion of the lifts, water pumps, electrical fittings, electro, mechanical and environment requirements, entrance lobby/s, plinth protection, paving of areas appertain and all other requirements as may be prescribed in the Agreement of sale of the building or wing in which the said Apartment is Page 8 of 24 located. viii. Balance Amount of Rs. /- (Rupees ) against and at the time of handing over of the possession of the Apartment to the Allottee on or after receipt of occupancy certificate or completion certificate. 1(d) The Total Price above excludes Taxes (consisting of tax paid or payable by the Promoter/Developer by way of Value Added Tax, Service Tax, and Cess or any other similar taxes which may be levied, in connection with the construction of and carrying out the Project payable by the Promoter/Developer) up to the date of handing over the possession of the [Apartment/Plot]. 1(e) The Total Price is escalation-free, save and except escalations/increases, due to increase on account of development charges payable to the competent authority and/or any other increase in charges which may be levied or imposed by the competent authority Local Bodies/Government from time to time. The Promoter/Developer undertakes and agrees that while raising a demand on the Allottee for increase in development charges, cost, or levies imposed by the competent authorities etc., the Promoter/Developer shall enclose the said notification/order/rule/regulation published/issued in that behalf to that effect alongwith the demand letter being issued to the Allottee, which shall only be applicable on subsequent payments. 1(f) The Promoter/Developer may allow, in its sole discretion, a rebate for early payments of equal instalments payable by the Allottee by discounting such early payments @ % per annum for the period by which the respective instalment has been preponed. The provision for allowing rebate and such rate of rebate shall not be subject to any revision/withdrawal, once granted to an Allottee by the Promoter/Developer. 1(g) T h e Promoter/Developer shall confirm the final carpet area that has been allotted to the Allottee after the construction of the building is complete and the occupancy certificate is granted by the competent authority, by furnishing details of the changes, if any, in the carpet area, subject to a variation cap of three percent. The total price payable for the carpet area shall be recalculated upon confirmation by the Promoter/Developer. If there is any reduction in the carpet area within the defined limit then Promoter/Developer shall refund the excess money paid by Allottee within forty-five days with annual interest at the rate specified in the Rules, from the date when such an excess amount was paid by the Allottee. If there is any increase in the carpet area allotted to Allottee, the Promoter/Developer shall demand additional amount from the Allottee as per the next milestone of the Payment Plan. All these monetary adjustments shall be made at the same rate per square meter as agreed in Clause 1(a) of this Agreement. 1(h) The Allottee authorizes the Promoter/Developer to adjust/appropriate all payments made by him/her under any head(s) of dues against lawful outstanding, if any, in his/her name as the Promoter/Developer may in its sole discretion deem fit and the Allottee undertakes not to object/demand/direct the Promoter/Developer to adjust his payments in any manner. Page 9 of 24 Note: Each of the instalments mentioned in the sub clause (ii) and (iii) shall be further subdivided into multiple instalments linked to number of basements/podiums/floors in case of multi-storied building /wing. 2. The Promoter/Developer hereby agrees to observe, perform and comply with all the terms, conditions, stipulations and restrictions if any, which may have been imposed by the concerned local authority at the time of sanctioning the said plans or thereafter and shall, before handing over possession of the Apartment to the Allottee, obtain from the concerned local authority occupancy and/or completion certificates in respect of the Apartment. Time is essence for the Promoter/Developer as well as the Allottee. The Promoter/Developer shall abide by the time schedule for completing the project and handing over the [Apartment/Plot] to the Allottee and the common areas to the association of the allottees after receiving the occupancy certificate or the completion certificate or both, as the case may be. Similarly, the Allottee shall make timely payments of the instalment and other dues payable by him/her and meeting the other obligations under the Agreement subject to the simultaneous completion of construction by the Promoter/Developer as provided in clause 1 (c) herein above. (“Payment Plan”). 3. The Promoter/Developer hereby declares that the Floor Space Index available as on date in respect of the project land is square meters only and Promoter/Developer has planned to utilize Floor Space Index of by availing of TDR or FSI available on payment of premiums or FSI available as incentive FSI by implementing various scheme as mentioned in the Development Control Regulation or based on expectation of increased FSI which may be available in future on modification to Development Control Regulations, which are applicable to the said Project. The Promoter/Developer has disclosed the Floor Space Index of as proposed to be utilized by him on the project land in the said Project and Page 10 of 24 Allottee has agreed to purchase the said Apartment based on the proposed construction and sale of apartments to be carried out by the Promoter/Developer by utilizing the proposed FSI and on the understanding that the declared proposed FSI shall belong to Promoter/Developer only. If the Promoter/Developer fails to abide by the time schedule for completing the project and handing over the [Apartment/Plot] to the Allottee, the Promoter/Developer agrees to pay to the Allottee, who does not intend to withdraw from the project, interest as specified in the Rule, on all the amounts paid by the Allottee, for every month of delay, till the handing over of the possession. The Allottee agrees to pay to the Promoter/Developer, interest as specified in the Rule, on all the delayed payment which become due and payable by the Allottee to the Promoter/Developer under the terms of this Agreement from the date the said amount is payable by the allottee(s) to the Promoter/Developer. Without prejudice to the right of Promoter/Developer to charge interest in terms of sub clause 4.1 above, on the Allottee committing default in payment on due date of any amount due and payable by the Allottee to the Promoter/Developer under this Agreement (including his/her proportionate share of taxes levied by concerned local authority and other outgoings) and on the allottee committing three defaults of payment of instalments, the Promoter/Developer shall at his own option, may terminate this Agreement: Provided that, Promoter/Developer shall give notice of fifteen days in writing to the Allottee, by Registered Post AD at the address provided by the allottee and mail at the e-mail address provided by the Allottee, of his intention to terminate this Agreement and of the specific breach or breaches of terms and conditions in respect of which it is intended to terminate the Agreement. If the Allottee fails to rectify the breach or breaches mentioned by the Promoter/Developer within the period of notice then at the end of such notice period, Promoter/Developer shall be entitled to terminate this Agreement. Provided further that upon termination of this Agreement as aforesaid, the Promoter/Developer shall refund to the Allottee (subject to adjustment and recovery of any agreed liquidated damages or any other amount which may be payable to Promoter/Developer) within a period of thirty days of the termination, the instalments of sale consideration of the Apartment which may till then have been paid by the Allottee to the Promoter/Developer. 5. The fixtures and fittings with regard to the flooring and sanitary fittings and amenities like one or more lifts with particular brand, or price range (if unbranded) to be provided by the Promoter/Developer in the said building and the Apartment as are set out in Annexure 'E', annexed hereto. 6. The Promoter/Developer shall give possession of the Apartment to the Allottee on or before day of 20 . If the Promoter/Developer fails or neglects to give possession of the Apartment to the Allottee on account of reasons beyond his control and of his agents by the aforesaid date then the Promoter/Developer shall be liable on demand to refund to the Allottee the amounts already received by him in respect of the Apartment with interest at Page 111 of 24 the same rate as may mentioned in the clause 4.1 herein above from the date the Promoter/Developer received the sum till the date the amounts and interest thereon is repaid. Provided that the Promoter/Developer shall be entitled to reasonable extension of time for giving delivery of Apartment on the aforesaid date, if the completion of building in which the Apartment is to be situated is delayed on account of - (i) war, civil commotion or act of God ; (ii) any notice, order, rule, notification of the Government and/or other public or competent authority/court. Procedure for taking possession - The Promoter/Developer, upon obtaining the occupancy certificate from the competent authority and the payment made by the Allottee as per the agreement shall offer in writing the possession of the [Apartment/Plot], to the Allottee in terms of this Agreement to be taken within 3 (three months from the date of issue of such notice and the Promoter/Developer shall give possession of the [Apartment/Plot] to the Allottee. The Promoter/Developer agrees and undertakes to indemnify the Allottee in case of failure of fulfilment of any of the provisions, formalities, documentation on part of the Promoter/Developer. The Allottee agree(s) to pay the maintenance charges as determined by the Promoter/Developer or association of Allottees, as the case may be. The Promoter/Developer on its behalf shall offer the possession to the Allottee in writing within 7 days of receiving the occupancy certificate of the Project. 7. The Allottee shall take possession of the Apartment within 15 days of the written notice from the Promoter to the Allottee intimating that the said Apartments are ready for use and occupancy: Failure of Allottee to take Possession of [Apartment/Plot]: Upon receiving a written intimation from the Promoter/Developer as per clause 8.1, the Allottee shall take possession of the [Apartment/Plot] from the Promoter/Developer by executing necessary indemnities, undertakings and such other documentation as prescribed in this Agreement, and the Promoter/Developer shall give possession of the [Apartment/Plot] to the allottee. In case the Allottee fails to take possession within the time provided in clause 8.1 such Allottee shall continue to be liable to pay maintenance charges as applicable. If within a period of five years from the date of handing over the Apartment to the Allottee, the Allottee brings to the notice of the Promoter/Developer any structural defect in the Apartment or the building in which the Apartment are situated or any defects on account of workmanship, quality or provision of service, then, wherever possible such defects shall be rectified by the Promoter/Developer at his own cost and in case it is not possible to rectify such defects, then the Allottee shall be entitled to receive from the Promoter/Developer, compensation for such defect in the manner as provided under the Act. 8. The Allottee shall use the Apartment or any part thereof or permit the same to be used only for purpose of *residence/office/show-room/shop/godown Page 112 of 24 for carrying on any industry or business.(*strike of which is not applicable) He shall use the garage or parking space only for purpose of keeping or parking vehicle. 9. The Allottee along with other Allottee(s)s of Apartments in the building shall join in forming and registering the Society or Association or a Limited Company to beknown by such name as the Promoter/Developer may decide and for this purpose also from time to time sign and execute the application for registration and/or membership and the other papers and documents necessary for the formation and registration of the Society or Association or Limited Company and for becoming a member, including the bye-laws of the proposed Society and duly fill in, sign and return to the Promoter/Developer within seven days of the same being forwarded by the Promoter/Developer to the Allottee, so as to enable the Promoter/Developer to register the common organization of Allottee. No objection shall be taken by the Allottee if any, changes or modifications are made in the draft bye-laws, or the Memorandum and/or Articles of Association, as may be required by the Registrar of Co- operative Societies or the Registrar of Companies, as the case may be, or any other Competent Authority. The Promoter/Developer shall, within three months of registration of the Society or Association or Limited Company, as aforesaid, cause to be transferred to the society or Limited Company all the right, title and the interest of the Vendor/Lessor/Original Owner/Promoter/Developer and/or the owners in the said structure of the Building or wing in which the said Apartment is situated. The Promoter/Developer shall, within three months of registration of the Federation/apex body of the Societies or Limited Company, as aforesaid, cause to be transferred to the Federation/Apex body all the right, title and the interest of the Vendor/Lessor/Original Owner/Promoter/Developer and/or the owners in the project land on which the building with multiple wings or buildings are constructed. Within 15 days after notice in writing is given by the Promoter/Developer to the Allottee that the Apartment is ready for use and occupancy, the Allottee shall be liable to bear and pay the proportionate share (i.e. in proportion to the carpet area of the Apartment) of outgoings in respect of the project land and Building/s namely local taxes, betterment charges or such other levies by the concerned local authority and/or Government water charges, insurance, common lights, repairs and salaries of clerks bill collectors, chowkidars, sweepers and all other expenses necessary and incidental to the management and maintenance of the project land and building/s. Until the Society or Limited Company is formed and the said structure of the building/s or wings is transferred to it, the Allottee shall pay to the Promoter/Developer such proportionate share of outgoings as may be determined. The Allottee further agrees that till the Allottee's share is so determined the Allottee shall pay to the Promoter/Developer provisional monthly contribution of Rs. per month towards the outgoings. The amounts so paid by the Allottee to the Promoter/Developer shall not carry any interest and remain with the Page 113 of 24 Promoter/Developer until a conveyance/assignment of lease of the structure of the building or wing is executed in favour of the society or a limited company as aforesaid. On such conveyance/assignment of lease being executed for the structure of the building or wing the aforesaid deposits (less deduction provided for in this Agreement) shall be paid over by the Promoter/Developer to the Society or the Limited Company, as the case may be. 10. The Allottee shall on or before delivery of possession of the said premises keep deposited with the Promoter/Developer, the following amount :- (i) Rs. for share money, application entrance fee of the Society or Limited Company/Federation/ Apex body. (ii) Rs. for formation and registration of the Society or Limited Company/Federation/ Apex body. (iii) Rs. for proportionate share of taxes and other charges/levies in respect of the Society or Limited Company/Federation/ Apex body (iv) Rs. for deposit towards provisional monthly contribution towards outgoings of Society or Limited Company/Federation/ Apex body. (v) Rs. For Deposit towards Water, Electric, and other utility and services connection charges & (vi) Rs. for deposits of electrical receiving and Sub Station provided in Layout 11. The Allottee shall pay to the Promoter/Developer a sum of Rs.. for meeting all legal costs, charges and expenses, including professional costs of the Attorney-at- Law/Advocates of the Promoter/Developer in connection with formation of the said Society, or Limited Company, or Apex Body or Federation and for preparing its rules, regulations and bye-laws and the cost of preparing and engrossing the conveyance or assignment of lease. 12. At the time of registration of conveyance or Lease of the structure of the building or wing of the building, the Allottee shall pay to the Promoter/Developer, the Allottees' share of stamp duty and registration charges payable, by the said Society or Limited Company on such conveyance or lease or any document or instrument of transfer in respect of the structure of the said Building /wing of the building. At the time of registration of conveyance or Lease of the project land, the Allottee shall pay to the Promoter/Developer, the Allottees' share of stamp duty and registration charges payable, by the said Apex Body or Federation on such conveyance or lease or any document or instrument of transfer in respect of the structure of the said land to be executed in favour of the Apex Body or Federation. Page 114 of 24 13. REPRESENTATIONS AND WARRANTIES OF THE PROMOTER/DEVELOPER The Promoter/Developer hereby represents and warrants to the Allottee as follows: i. The Promoter/Developer has clear and marketable title with respect to the project land; as declared in the title report annexed to this agreement and has the requisite rights to carry out development upon the project land and also has actual, physical and legal possession of the project land for the implementation of the Project; ii. The Promoter/Developer has lawful rights and requisite approvals from the competent Authorities to carry out development of the Project and shall obtain requisite approvals from time to time to complete the development of the project; iii. There are no encumbrances upon the project land or the Project except those disclosed in the title report; iv. There are no litigations pending before any Court of law with respect to the project land or Project except those disclosed in the title report; v. All approvals, licenses and permits issued by the competent authorities with respect to the Project, project land and said building/wing are valid and subsisting and have been obtained by following due process of law. Further, all approvals, licenses and permits to be issued by the competent authorities with respect to the Project, project land and said building/wing shall be obtained by following due process of law and the Promoter/Developer has been and shall, at all times, remain to be in compliance with all applicable laws in relation to the Project, project land, Building/wing and common areas; vi. The Promoter/Developer has the right to enter into this Agreement and has not committed or omitted to perform any act or thing, whereby the right, title and interest of the Allottee created herein, may prejudicially be affected; vii. The Promoter/Developer has not entered into any agreement for sale and/or development agreement or any other agreement / arrangement with any person or party with respect to the project land, including the Project and the said [Apartment/Plot] which will, in any manner, affect the rights of Allottee under this Agreement; viii. The Promoter/Developer confirms that the Promoter/Developer is not restricted in any manner whatsoever from selling the said [Apartment/Plot]to the Allottee in the manner contemplated in this Agreement; ix. At the time of execution of the conveyance deed of the structure to the association of Allottees the Promoter/Developer shall handover lawful, vacant, peaceful, physical possession of the common areas of the Structure to the Association of the Allottees; x. The Promoter/Developer has duly paid and shall continue to pay and discharge undisputed governmental dues, rates, charges and taxes and other monies, levies, impositions, premiums, damages and/or penalties and other outgoings, whatsoever, payable with respect to the said project to the competent Authorities; xi. No notice from the Government or any other local body or authority or any legislative enactment, government ordinance, order, notification (including any notice for acquisition or requisition of the said property) has been received or served upon the Promoter/Developer in respect of the project Page 20 of 20 land and/or the Project except those disclosed in the title report. 14. The Allottee/s or himself/themselves with intention to bring all persons into whosoever hands the Apartment may come, hereby covenants with the Promoter/Developer as follows :- i. To maintain the Apartment at the Allottee's own cost in good and tenantable repair and condition from the date that of possession of the Apartment is taken and shall not do or suffer to be done anything in or to the building in which the Apartment is situated which may be against the rules, regulations or bye-laws or change/alter or make addition in or to the building in which the Apartment is situated and the Apartment itself or any part thereof without the consent of the local authorities, if required. ii. Not to store in the Apartment any goods which are of hazardous, combustible or dangerous nature or are so heavy as to damage the construction or structure of the building in which the Apartment is situated or storing of which goods is objected to by the concerned local or other authority and shall take care while carrying heavy packages which may damage or likely to damage the staircases, common passages or any other structure of the building in which the Apartment is situated, including entrances of the building in which the Apartment is situated and in case any damage is caused to the building in which the Apartment is situated or the Apartment on account of negligence or default of the Allottee in this behalf, the Allottee shall be liable for the consequences of the breach. iii. To carry out at his own cost all internal repairs to the said Apartment and maintain the Apartment in the same condition, state and order in which it was delivered by the Promoter/Developer to the Allottee and shall not do or suffer to be done anything in or to the building in which the Apartment is situated or the Apartment which may be contrary to the rules and regulations and bye-laws of the concerned local authority or other public authority. In the event of the Allottee committing any act in contravention of the above provision, the Allottee shall be responsible and liable for the consequences thereof to the concerned local authority and/or other public authority. iv. Not to demolish or cause to be demolished the Apartment or any part thereof, nor at any time make or cause to be made anyaddition or alteration of whatever nature in or to the Apartment or any part thereof, nor any alteration in the elevation and outside colour scheme of the building in which the Apartment is situated and shall keep the portion, sewers, drains and pipes in the Apartment and the appurtenances thereto in good tenantable repair and condition, and in particular, so as to support shelter and protect the other parts of the building in which the Apartment is situated and shall not chisel or in any other manner cause damage to columns, beams, walls, slabs or RCC, Pardis or other structural members in the Apartment without the prior written permission of the Promoter/Developer and/or the Society or the Limited Company. v. Not to do or permit to be done any act or thing which may render void or voidable any insurance of the project land and the building in which the Apartment is situated or any part thereof or whereby any increased premium shall become payable in respect of the insurance. vi. Not to throw dirt, rubbish, rags, garbage or other refuse or permit the same to be thrown from the said Apartment in the compound or any portion of the project land and the building in which the Apartment is situated. vii. Pay to the Promoter/Developer within fifteen days of demand by the Promoter/Developer, his share of security deposit demanded by the concerned local authority or Government or giving water, electricity or any Page 20 of 20 other service connection to the building in which the Apartment is situated. viii. To bear and pay increase in local taxes, water charges, insurance and such other levies, if any, which are imposed by the concerned local authority and/or Government and/or other public authority, on account of change of user of the Apartment by the Allottee for any purposes other than for purpose for which it is sold. ix. The Allottee shall not let, sub-let, transfer, assign or part with interest or benefit factor of this Agreement or part with the possession of the Apartment until all the dues payable by the Allottee to the Promoter/Developer under this Agreement are fully paid up. x. The Allottee shall observe and perform all the rules and regulations which the Society or the Limited Company or Apex Body or Federation may adopt at its inception and the additions, alterations or amendments thereof that may be made from time to time for protection and maintenance of the said building and the Apartments therein and for the observance and performance of the Building Rules, Regulations and Bye-laws for the time being of the concerned local authority and of Government and other public bodies. The Allottee shall also observe and perform all the stipulations and conditions laid down by the Society/Limited Company/Apex Body/Federation regarding the occupancy and use of the Apartment in the Building and shall pay and contribute regularly and punctually towards the taxes, expenses or other out-goings in accordance with the terms of this Agreement. xi. Till a conveyance of the structure of the building in which Apartment is situated is executed in favour of Society/Limited Society, the Allottee shall permit the Promoter/Developer and their surveyors and agents, with or without workmen and others, at all reasonable times, to enter into and upon the said buildings or any part thereof to view and examine the state and condition thereof. xii. Till a conveyance of the project land on which the building in which Apartment is situated is executed in favour of Apex Body or Federation, the Allottee shall permit the Promoter/Developer and their surveyors and agents, with or without workmen and others, at all reasonable times, to enter into and upon the project land or any part thereof to view and examine the state and condition thereof. 15. The Promoter/Developer shall maintain a separate account in respect of sums received by the Promoter/Developer from the Allottee as advance or deposit, sums received on account of the share capital for the promotion of the Co-operative Society or association or Company or towards the out goings, legal charges and shall utilize the amounts only for the purposes for which they have been received. 15A. In case the transaction being executed by this Agreement between the promoter and the allottee is facilitated by a registered real Estate Agent, all amounts (including taxes) agreed as payable remuneration / fees / charges / for services / commission brokerage to the said registered real estate agent, shall be paid by the promoter / allottee / both, as the case may be, in accordance with the agreed terms of payment. 16. Nothing contained in this Agreement is intended to be nor shall be construed as a grant, demise or assignment in law, of the said Apartments or of the said Plot and Building or any part thereof. The Allottee shall have no claim save and except in respect of the Apartment hereby agreed to be sold to him and all open spaces, parking spaces, lobbies, staircases, terraces recreation spaces, will remain the property of the Promoter/Developer until the said structure of the building is transferred to the Society/Limited Company or other body and until the project land is transferred to the Apex Body /Federation as hereinbefore mentioned. Page 20 of 20 17. PROMOTER/DEVELOPER SHALL NOT MORTGAGE OR CREATE A CHARGE After the Promoter/Developer executes this agreement he shall not mortgage or create a charge on the *[Apartment/] and if any such mortgage or charge is made or created then notwithstanding anything contained in any other law for the time being in force, such mortgage or charge shall not affect the right and interest of the Allottee who has taken or agreed to take such [Apartment/plot]. 18. BINDING EFFECT Forwarding this Agreement to the Allottee by the Promoter/Developer does not create a binding obligation on the part of the Promoter/Developer or the Allottee until, firstly, the Allottee signs and delivers this Agreement with all the schedules along with the payments due as stipulated in the Payment Plan within 30 (thirty) days from the date of receipt by the Allottee and secondly, appears for registration of the same before the concerned Sub- Registrar as and when intimated by the Promoter/Developer. If the Allottee(s) fails to execute and deliver to the Promoter/Developer this Agreement within 30 (thirty) days from the date of its receipt by the Allottee and/or appear before the Sub-Registrar for its registration as and when intimated by the Promoter/Developer, then the Promoter/Developer shall serve a notice to the Allottee for rectifying the default, which if not rectified within 15 (fifteen) days from the date of its receipt by the Allottee, application of the Allottee shall be treated as cancelled and all sums deposited by the Allottee in connection therewith including the booking amount shall be returned to the Allottee without any interest or compensation whatsoever. 19. ENTIRE AGREEMENT This Agreement, along with its schedules and annexures, constitutes the entire agreement between the Parties with respect to the subject matter hereof and supersedes any and all understandings, any other agreements, allotment letter, correspondences, arrangements whether written or oral, if any, between the Parties in regard to the said apartment/plot/building, as the case may be. 20. RIGHT TO AMEND This Agreement may only be amended through written consent of the Parties. Page 20 of 20 21. PROVISIONS OF THIS AGREEMENT APPLICABLE TO ALLOTTEE/ SUBSEQUENT ALLOTTEES: It is clearly understood and so agreed by and between the Parties hereto that all the provisions contained herein and the obligations arising hereunder in respect of the Project shall equally be applicable to and enforceable against any subsequent Allottees of the [Apartment/Plot], in case of a transfer, as the said obligations go along with the [Apartment/Plot] for all intents and purposes. 22. SEVERABILITY If any provision of this Agreement shall be determined to be void or unenforceable under the Act or the Rules and Regulations made thereunder or under other applicable laws, such provisions of the Agreement shall be deemed amended or deleted in so far as reasonably inconsistent with the purpose of this Agreement and to the extent necessary to conform to Act or the Rules and Regulations made thereunder or the applicable law, as the case may be, and the remaining provisions of this Agreement shall remain valid and enforceable as applicable at the time of execution of this Agreement. 23. METHOD OF CALCULATION OF PROPORTIONATE SHARE WHEREVER REFERRED TO IN THE AGREEMENT Wherever in this Agreement it is stipulated that the Allottee has to make any payment, in common with other Allottee(s) in Project, the same shall be in proportion to the carpet area of the [Apartment/Plot] to the total carpet area of all the [Apartments/Plots] in the Project. 24. FURTHER ASSURANCES Both Parties agree that they shall execute, acknowledge and deliver to the other such instruments and take such other actions, in additions to the instruments and actions specifically provided for herein, as may be reasonably required in order to effectuate the provisions of this Agreement or of any transaction contemplated herein or to confirm or perfect any right to be created or transferred hereunder or pursuant to any such transaction. 25. PLACE OF EXECUTION The execution of this Agreement shall be complete only upon its execution by the Promoter/Developer through its authorized signatory at the Promoter/Developer’s Office, or at some other place, which may be mutually agreed between the Promoter/Developer and the Allottee, in after the Agreement is duly executed by the Allottee and the Promoter/Developer or simultaneously with the execution the said Agreement shall be registered at the office of the Sub-Registrar. Hence this Agreement shall be deemed to have been executed at . 26. The Allottee and/or Promoter/Developer shall present this Agreement as well as the conveyance/assignment of lease at the proper registration office of registration within the time limit prescribed by the Registration Act and the Promoter/Developer will attend such office and admit execution thereof. 27. That all notices to be served on the Allottee and the Promoter/Developer as contemplated by this Agreement shall be deemed to have been duly served if sent to the Allottee or the Promoter/Developer by Registered Post A.D and notified Email ID/Under Certificate of Posting at their respective addresses specified below: Page 20 of 20 Name of Allottee : (Allottee’s Address) : Notified Email ID: Name of Vendor / Promoter/Developer name : Promoter / Developer name : M/s MAHARANA & BOSE ASSOCIATES Acting through its Partners (1)MR. VILAS S/o SAHEBRAO DESHMUKH and (2) MR. RAJENDRANATH MANINDRANATH BOSE (Promoter Address) : Having its Office at 1st Floor, ‘Shivhare Bhawan’, Koshtipura, Sitabuldi, Nagpur, Pin Code No. 440012 Notified Email ID: It shall be the duty of the Allottee and the Promoter/Developer to inform each other of any change in address subsequent to the execution of this Agreement in the above address by Registered Post failing which all communications and letters posted at the above address shall be deemed to have been received by the Promoter/Developer or the Allottee, as the case may be. 28. JOINT ALLOTTEES That in case there are Joint Allottees all communications shall be sent by the Promoter/Developer to the Allottee whose name appears first and at the address given by him/her which shall for all intents and purposes to consider as properly served on all the Allottees. 29. Stamp Duty and Registration: The charges towards stamp duty and Registration of this Agreement shall be borne by the allottee. 30. Dispute Resolution: Any dispute between parties shall be settled amicably. In case of failure to settled the dispute amicably, which shall be referred to the Competent Authority as per the provisions of the Real Estate (Regulation and Development) Act, 2016, Rules and Regulations, thereunder. 31. GOVERNING LAW That the rights and obligations of the parties under or arising out of this Agreement shall be construed and enforced in accordance with the laws of India for the time being in force and the courts will have the jurisdiction for this Agreement IN WITNESS WHEREOF parties hereinabove named have set their respective hands and signed this Agreement for sale at NAGPUR (city/town name) in the presence of attesting witness, signing as such on the day first above written. Page 20 of 20 First Schedule Above Referred to Description of the freehold/leasehold land and all other details THE UNDIVIDED PERCENT share and interest in ALL THAT Piece and Parcel of land bearing Amalgamated Plot No. 16-17, containing by admeasurements 2957.00 Sq. Mtrs. (i.e. 31829.148 Sq. Ft.) being a portion of the entire land bearing Khasra No. 35/5 of Mouza – GOREWADA, Patwari Halka No. 8-A and including all other easementary rights appurtenant and belonging thereto, bearing City Survey No. 37 and Sheet No. 32/32, situated at Grewada, Nagpur, within the limits of the Nagpur Municipal Corporation Ward No. 61 in Tahsil and District – NAGPUR and bounded as under: ON THE EAST – 9.00 MTRS. WIDE ROAD. ON THE WEST - . ON THE NORTH – . ON THE SOUTH – . Second Schedule Above Referred to Here set out the nature, extent and description of common areas and facilities. A.)Description of the common areas provided: Type of common Proposed Date Proposed Size/area of the areas of Occupancy Date of common areas provided Certificate handover for provided use i. ii. iii. B.) Facilities/ amenities provided/to be provided within the building including in the common area of the building: Type Phase Proposed Proposed Size/area of FSI of name/ Date of Date of the Utilized facilitie number Occupancy handing over facilities or free s/ Certificate to the / of FSI ameniti Society/comm amenities es on provide organization d i. ii. iii. C.) Facilities/ amenities provided/to be provided within the Layout and/or common area of the Layout: Page 20 of 20 Type Phase Proposed Proposed Size/area of FSI of name/ Date of Date of the Utilized facilitie number Occupancy handing over facilities or free s/ Certificate to the Society / of FSI ameniti / common amenities es organization provide d i. ii. iii. D.) The size and the location of the facilities / amenities in form of open spaces (RG / PG etc.) provided / to be provided within the plot and / or within the layout. Type of open Phase Size open Proposed Proposed Date spaces name/ spaces to Date of of handing (RG/PG) to number be availability over to the be provided provided for use common organizat ion i. ii. iii. E.) Details and specifications of the lifts: Type Lift Total no. of Number of Speed (passenger/servi Lifts passenger or (mtr/sec) ce/str provided carrying capacity in etcher/goods/fir weight (kg) e evacuation/any other i. ii. iii. Note: At ‘A’: to provide the details of the common areas provided for the project. At ‘B’: to provide the details of the facilities/amenities provided within the building and in the common area of the building. At ‘C’: to provide the details of the facilities/amenities provided within the Layout and/or common area of the Layout. At ‘D’: to provide the details of the facilities/amenities provided in form of open spaces (RG/ PGetc.) provided / to be provided within the plot and / or within the layout. At ‘E’: to provide the details and specifications of the lifts. SIGNED AND DELIVERED BY THE WITHIN NAMED Allottee: (including joint buyers) Please affix Please affix photograph photograph and sign and sign (1) across the across the photograph photograph (2) Page 20 of 20 At on in the presence of WITNESSES: 1. Name : Signature : 2. Name : Signature : SIGNED AND DELIVERED BY THE WITHIN NAMED Vendor/Promoter/Developer: M/s MAHARANA & BOSE ASSOCIATES Please affix Please affix Through its Partners photograph photograph and sign and sign across the across the photograph photograph (1) (VILAS SAHEBRAO DESHMUKH) Please affix Please affix photograph photograph (2) and sign and sign (RAJENDRANATH MANINDRANATH BOSE) across the across the Partners photograph photograph (Authorized Signatory) WITNESSES: Name Signature Name Signature Note – Execution clauses to be finalized in individual cases having regard to the constitution of the parties to the Agreement. SCHEDULE ‘A’ PLEASE INSERT DESCRIPTION OF THE [APARTMENT/PLOT] AND THE GARAGE/CLOSED PARKING (IF APPLICABLE) ALONG WITH BOUNDARIES IN ALL FOUR DIRECTIONS ALL THAT R.C.C. Superstructure comprising Apartment No. covering a Carpet area of square meters, on the FLOOR along with Parking area of square meters of a Building proposed to be constructed on the aforesaid Plot of land to be known and styled as “WING-A-SATPUDA and WING-B-SAHYADRI APARTMENTS” and bounded as under- ON THE EAST - 9.00 MTRS. WIDE ROAD AND PLOT NO. 15, ON THE WEST - LAND OF KH NO. 37/2, ON THE NORTH - PLOT NO. 18, Page 20 of 20 ON THE SOUTH - LAND OF KH NO. 37/1. No. RE.: Place: SCHEDULE ‘B’ FLOOR PLAN OF THE APARTMENT ANNEXURE – A Name of the Attorney at Law/Advocate, Address: Date: Title Report Details of the Title Report The Schedule Above Referred to (Description of property) Dated __________ day of ............... 20........ (Signed) Signature of Attorney-at-Law/Advocate ANNEXURE –B (Authenticated copies of Property Card or extract Village Forms VI or VII and XII or any other revenue record showing nature of the title of the Vendor/Lessor/Original Owner/Promoter/Developer to the project land). ANNEXURE –C-1 (Authenticated copies of the plans of the Layout as approved by the concerned Local Authority) ANNEXURE - C-2 (Authenticated copies of the plans of the Layout as proposed by the Promoter and according to which the construction of the buildings and open spaces are proposed to be provided for on the said project) ANNEXURE -D (Authenticated copies of the plans and specifications of the Apartment agreed to be purchased by the Allottee as approved by the concerned local authority) ANNEXURE – E (Specification and amenities for the Apartment), ANNEXURE –F (Authenticated copy of the Registration Certificate of the Project granted by the Real Estate Regulatory Authority) Received of and from the Allottee above named the sum of Rupees on execution of this agreement towards Earnest Money Deposit or application fee I say received. The Promoter/s. Page 20 of 20