AGREEMENT FOR SALE THIS AGREEMENT FOR SALE is made and entered into at Nagpur on this _____ day of ______________________ 2023: BY AND BETWEEN Luxora Infrastructure Private Limited, (PAN No. AABCL2854K, CIN: U65929MH2007PTC166943), a company incorporated under the Indian Companies Act, 1956 and having its registered office at Unit No 150, Avior Corporate Park , Nirmal Galaxy, LBS Road, Mulund (West), Mumbai – 400080 and also having an office in Nagpur located at The Glade, Ensaara Metropark, Mouja Pipla, Nagpur (MH) 440034, hereinafter referred to as the “Promoter” (which expression shall unless it be repugnant to the subject, context or meaning thereof, be deemed to mean and include its successors and assigns) of the One Part; AND _______________________________________ having his/her/their/its address as stated in Annexure “A” hereto and hereinafter referred to as the “Allottee” (which expression shall un- less it be repugnant to the subject context or meaning thereof, be deemed to mean and include (a) in the case of an individual or individuals, his, her or their respective heirs, executors, admin- istrators and permitted assigns; (b) in the case of a body corporate, its successors and permitted assigns; (c) in the case of a partnership firm, the partners for the time being and from time to time constituting the firm and the survivors or survivor of them and the heirs, executors and ad- ministrators of the last survivor of them and his, her or their permitted assigns; (d) in the case of Hindu Undivided Family, the Karta and the members for the time being and from time to time of the coparcenary and the survivors or survivor of them and the heirs, executors and administra- tors of the last survivor of them and his, her or their permitted assigns; or (e) in the case of a Trust, the Trustees for the time being and from time to time of the Trust and the survivors or sur- vivor of them and the heirs, executors and administrators of the last survivor of them and his, her or their permitted assigns) of the Other Part; The Promoter and the Allottee shall, wherever the context requires, be referred to individually as “Party” and collectively as “Parties” hereto. RECITALS WHEREAS:- A. The Government of Maharashtra through the Urban Development Department (hereinafter referred to as the “Government”), acting under the provisions of Sections 20(4) and 37 of the Maharashtra Regional and Town Planning Act, 1966; has sanctioned modification of the Development Control Regulations of all the Municipal Corporations, New Town Development Authorities, Special Planning Authorities, Municipal Councils and also in the Development Control Regulations of the Regional Plans of the State of Maharashtra by incorporating Development Control Regulations exclusively for Special Townships and accordingly has vide Notification bearing No. TPS 2405/Nagpur R.P.DCR/ UD-9 dated February 17, 2006 modified the Regional Plan for Nagpur District Region. Vide Notification bearing No. TPS-1816/CR-368/15/20(3)/UD-13 dated November 09, 2016 and Notification No. TPS-1816-CR.368-16-part-1-DP-ITP-UD-13, dated 08th March 2019 has further modified and sanctioned in order to incorporate the regulations for Development of Integrated Townships Project (hereinafter collectively referred to as “Township Regulations”). B. The Promoter has acquired and/or is well and sufficiently entitled to all that freehold piece or parcel of land or ground hereditaments located at Mouja Pipla Taluka and District Nagpur admeasuring approximately 54 hectares equivalent to approximately 133 acres which is more particularly described in the Schedule hereunder written (hereinafter referred to as the “Ensaara Property”). In accordance with the Township Regulations, the Promoter has planned and is in the process of developing and constructing an integrated township to be known as “Ensaara Metropark” on all/part of the Ensaara Property, consisting of several plots, multi-storied buildings containing residential and/or non-residential units, in several phases, along with required infrastructure, amenities, and facilities. C. In compliance with the Township Regulations, the Promoter has, in respect of the Ensaara Property, obtained from the Appropriate Authorities, the necessary approvals for the development of Ensaara Metropark. D. At present, as a part of the development of Ensaara Property, the Promoter, after having obtained necessary approvals from the Appropriate Authority (details of the key approvals are more particularly stated in Annexure “B” hereto), has commenced construction of a Unit forming part of the Project proposed to be constructed on the Project Land, which forms part of the Layout Land and Ensaara Property, in accordance with the Project Plan. The particulars of the Unit, Project and the Project Land are stated in Annexure “A” hereto). The Layout Land and the Project Land is shown in blue and red colour boundary lines respectively, on the plan annexed hereto as Annexure “C”. E. The Promoter has in compliance of the Real Estate (Regulation and Development) Act, 2016 (“Act”) and the Maharashtra Real Estate (Regulation and Development) (Registration of Real Estate Projects, Registration of Real Estate Agents, Rates of Interest and Disclosures on Website) Rules, 2017 (“Rules”), registered the Project as a “real estate project” as defined under the Act, with the Maharashtra Real Estate Regulatory Authority, having the registration number as more particularly stated in Annexure A hereto. An authenticated copy of the project registration certificate issued by the Maharashtra Real Estate Regulatory Authority is annexed hereto as Annexure “D”. F. For the Project, the Promoter has entered into a standard agreement with an Architect registered with the Council of Architects and has appointed a Chartered Engineer for the preparation of the design and drawings of the Project.The Promoter accepts professional supervision of the Architect and the Chartered Engineer until the complete development of the Project. From time to time the Promoter shall appoint various other contractors and sub-contractors for the development of the Project. Notwithstanding what is stated herein, the Promoter shall always be entitled to change any or all of the architects, engineers, contractors, sub-contractors etc, engaged in the development of Project, in their sole discretion without any recourse to the Allottee. The Allottee understands and accepts the same G. It is an express, essential, and integral terms and conditions of this Agreement that: (a) The Promoter has been desirous of developing an integrated township i.e. the Ensaara Metropark on the Ensaara Property (as has been enlarged and reduced from time to time) comprising of, inter alia, residential and non-residential buildings, plots, club houses, retail buildings, convenience stores, gardens, open spaces along with all the required infrastructure facilities including but not limited to water supply, sanitation, electric power, roads, telephone lines etc. in an orderly and systematic manner and also to manage and maintain Ensaara Metropark, in accordance with the Township Regulations. (b) The Promoter shall in its sole and unfettered discretion, undertake the development of building and/or several buildings on the Layout Land and shall further be entitled to register each of such building/s as independent ‘real estate projects’ under the Act with the Maharashtra Real Estate Regulatory Authority, if required from time to time. (c) The Promoter shall in its sole and unfettered discretion, undertake the development of different piece and parcels of land forming a part of the Ensaara Property either by itself or jointly with other developers and which may or may not be contiguous/adjoining the Layout Land and shall further be entitled to register any such development as independent “real estate projects’ under the Act with the Maharashtra Real Estate Regulatory Authority, if required from time to time (hereinafter referred to as the “Balance Projects”). The Ensaara Metropark Amenities and Facilities shall be ultimately held by the Apex Body, as provided herein, and/or managed through the Apex Body, as determined by the Promoter, in its sole discretion. (d) All the projects comprised in the Layout and forming part of the Layout Land shall have proportionate undivided interest in the limited common areas and facilities of the Layout Land which will be ultimately held by the Body Corporate(s) and/or the Apex Body, as the case maybe, as determined by the Promoter, in its sole discretion. (e) Pursuant to the modification/amendment of the erstwhile Township Regulations, the Promoter is now entitled to enhanced FSI in respect of the Ensaara Property and accordingly, the Promoter shall be applying for modification/amendments of the Approvals from the Appropriate Authorities in order to further utilize the enhanced FSI. The Promoter shall also be entitled to make variations, alterations, amendments or deletions to or in the plans/scheme of development of the Ensaara Metropark, or any part thereof, layout plans and Project Plan and/or Layout Plan including but not limiting to the relocating/ realignment of roads, water, power, sewerage, telephone, gas and other services and utility connections and lines, overhead/underground tanks, pumps, open spaces, parking spaces, club houses, convenience stores recreation areas, garden or playground spaces and all or any other areas, amenities and facilities as they may deem fit in their sole and unfettered discretion; or if the same are required by the Appropriate Authorities, but without affecting the rights and interests of the Allottee under this Agreement vis-a-vis the location of the Project, the location of the Unit in the Project and the area of the Unit. (f) The Promoter shall also be entitled to enlarge/reduce the area of the Ensaara Property and/or delete/de-notify all or part of Ensaara Metropark from the Township Regulations at any point in time. In such case of such deletion/denotificaton, the Allottee shall acknowledge and accept the same without any protest or demur. Further, the Allottee hereby agrees that he/she/it shall not have any claim against the Promoter in relation to such deletion/denotification. The Allottee shall have no claim whatsoever on any such denotified and/or deleted portion of Ensaara Metropark. The Allottee understands the same and hereby grants their unconditional consent to the same. (g) Notwithstanding what is stated hereinabove, the Allottee admits, acknowledges and confirms that the Promoter has disclosed and declared to the Allottee and the Allottee has understood and independently verified, that as per the existing proposed new Development Plan for Nagpur made by Nagpur Improvement Trust three roads were proposed on the Ensaara Property. The Promoter on September 29, 2015 has made necessary representations to the Nagpur Improvement Trust and the Hon’ble Collector, Nagpur stating that prior to the preparation of the proposed new Development Plan, for the Ensaara Property, the Promoter has already received all the necessary approvals from the Appropriate Authorities, for development of Ensaara Property as an integrated township in accordance with the Township Regulations. Upon such representations, the Appropriate Authorities have subsequently recommended for deletion of the said proposed roads. The details of such recommendations are available on the Nagpur Improvement Trust’s official website. The Promoter is in the process of revising the road alignment in accordance with the requirement of Appropriate Authorities and this may revise common areas, amenities and parking spaces of the Project/Layout/Ensaara Metropark accordingly. H. The Allottee has demanded from the Promoter and the Promoter has given inspection to the Allottee of all the documents of title in respect of the Project Land and the Approvals. The Allottee has independently verified the same and is satisfied in all respects thereto. The Allottee hereby confirms the same and waives the right to further investigate and/or raise any objections regarding the title of the Promoter to the Project Land. A copy of the title certificate issued by M/s Dwivedi & Khedkar Advocates and the Property Card and/or VII/XII extracts in respect of the Project Land are hereto annexed and marked as Annexure “E and Annexure “F” respectively. Further, the Allottee confirms that the Promoter has given to the Allottee inspection of the plans including the Ensaara Property, Project and Unit Plan (and any proposed revisions thereof), the aforesaid proposed new development plan, notifications, structural designs and specifications of the Unit and the Allottee has independently verified the same and is satisfied in all aspects thereto. I. After perusing and being completely satisfied with regard to the Approvals and title documents in respect of the Project and/or Project Land, the Allottee has agreed to acquire from the Promoter and the Promoter has agreed to grant unto the Allottee, the Unit at and for the Consideration and on the terms and conditions hereinafter contained. The Unit and Car Parking Space are more particularly described in Annexure A hereto. The Unit Plan is hereto annexed as Annexure “G” and the Project Plan is hereto annexed as Annexure “C”. The Unit Amenities and Facilities to be provided by the Promoter to the Allottee are more particularly stated in Annexure “H” annexed hereto. J. The Parties, being desirous of recording the terms and conditions of sale and purchase of the Unit, as agreed to between the Parties and as required under Section 13 of the Act read with the Rules, have executed this Agreement to bind one another as hereunder. NOW THEREFORE, in consideration of the foregoing and the mutual covenants, consideration and promises contained, the Parties intending to be bound legally, agree as follows: 1. DEFINITIONS AND CONSTRUCTION The Parties hereto confirm that all the recitals of this Agreement shall form a part and parcel of this operative part of the Agreement as if the same were reproduced verbatim herein. 1.1 Definitions In this Agreement each word or phrase listed below has the meaning designated herein. Other words or phrases used in this Agreement may be defined in the context in which they are used, and shall have the respective meaning designated therein, unless the context otherwise requires: 1.1.1 “Agreement” shall mean this Agreement for Sale and the Schedules, Annexures to this Agreement and amendments in writing thereto, if any; 1.1.2 “Apex Body” shall mean an association of persons duly incorporated registered or formed under the law being in force (at the relevant time) or a company incorporated under the Companies Act, 1956, or a co-operative society formed under the Maharashtra Co-operative Societies Act, 1960 or an association of apartment owners formed under the Maharashtra Apartment Ownership Act, 1970 or any such body corporate or organisation, as may be incorporated/registered by the Promoter in its discretion, under the prevalent laws at the appropriate time; the shareholders/members whereof, shall comprise of all the body corporates of the Balance Projects including the Body Corporate and the allottees of any stand-alone premises in the Ensaara Metropark which do not form a part of any body corporate, if any. 1.1.3 “Applicable Law” shall mean any statute, law, regulation, ordinance, rule, judgment, notification, rule of common law, order, decree, bye-law, permits, licenses, approvals, consents, authorizations, government approvals, directive, guidelines, requirement or other governmental restriction, or any similar form of decision of, or determination by, or any interpretation, policy or administration, having the force of law of any of the foregoing, by any authority having jurisdiction over the matter in question, whether in effect as of the date of this Agreement or thereafter. 1.1.4 “Appropriate Authority” or “Appropriate Authorities” shall mean the Government of Maharashtra and/or the Honourable Collector, Nagpur and/or the Nagpur Municipal Corporation and/or the Nagpur Improvement Trust, authorities under the Income Tax Act, 1961, the Maharashtra Real Estate Regulatory Authority and/or any other statutory body or quasi-judicial body to which the Ensaara Property and/or Ensaara Metropark is subjected to or may be subjected to in the future. 1.1.5 “Approvals” shall mean and include all licenses, permits, approvals, sanctions, consents obtained/ to be obtained from or granted/ to be granted by the Appropriate Authorities in connection with the development and construction of the Unit. 1.1.6 “Balance Projects” shall have the meaning ascribed to it in Recital G. 1.1.7 “Body Corporate” shall mean an association of persons duly incorporated or formed under any law for the time being in force or a company incorporated under the Companies Act, 1956, or a co-operative society formed under the Maharashtra Co- operative Societies Act, 1960 or an association of apartment owners formed under the Maharashtra Apartment Ownership Act, 1970 or any such body corporate or organisation, as may be incorporated/registered by the Promoter in its discretion, under the prevalent laws at the appropriate time for Layout, including the Project, the members whereof shall comprise of all transferees and/or allottees of the Layout and/or Project constructed on the Layout Land. 1.1.8 “Car Parking Space” shall mean the number of spaces for parking cars on the Layout Land which may either be a garage, closed parking space or the exclusive right to use an open parking, as more particularly stated and described in Annexure A hereto. 1.1.9 “Carpet Area” means the proposed carpet area of the Unit as stated in Annexure A hereto, as presently determined on the basis of net usable floor area of the Unit excluding the area covered by external walls, areas under service shafts, exclusive balcony or verandah area and exclusive open terrace areas, if any, but includes the area covered by the internal partition walls of the Unit 1.1.10 “Charges and Deposits” shall mean the charges, notified to the Allottee under the Notice of Possession and which are payable by the Allottee on or before the Possession Date, or as otherwise stated, and as specified in Annexure A hereto. 1.1.11 “Charges and Deposits Bank Account” shall mean the bank account created in respect of sums received by the Promoter from the Allottee as advance or deposit, sums received on account of the share capital for the promotion of the Body Corporate or towards the out goings, legal charges and shall utilize the amounts only for the purposes for which they have been received, particulars of which are stated in Annexure A hereto. 1.1.12 “Consideration” shall mean an amount to be paid by the Allottee to the Promoter in accordance with Annexure A hereto as and by way of consideration for sale of the Unit and the Car Parking Spaces in accordance with Annexure A hereto. 1.1.13 “Defects” shall mean shall mean any material structural defect caused due to use of defective material or components used in the construction of the Unit or failure to build in accordance with the Unit Plan but shall exclude wear and tear, loss or damage due to an event of Force Majeure, minor changes/cracks on account of any variation in temperature/weather, misuse, unauthorised or non-permitted alterations, renovations or repairs either by the Allottee or the allottee of any neighbouring or adjoining units or and loss or damage caused by any act, omission, negligence, and/or failure to undertake proper or effective care and maintenance as a prudent person would, either by the Allottee or the allottee of any neighbouring or adjoining units. 1.1.14 “Ensaara Metropark” shall mean the integrated township being developed by the Promoter on the Ensaara Property, or a part thereof, in accordance with the Township Regulations. 1.1.15 “Ensaara Metropark Amenities and Facilities” shall mean those common areas, infrastructure, amenities and facilities to be developed upon the Ensaara Property, in accordance with the Township Regulations, which shall be developed by the Promoter, in its discretion, in several phases and/or along with the Balance Projects as a part of the Ensaara Metropark, which are intended for the common use of, inter alia, the allottees, purchasers and occupants from time to time but shall exclude the Unit Amenities and Facilities. Part of the Ensaara Metropark Amenities and Facilities shall be made available on completion of the Project. 1.1.16 “Ensaara Metropark Management Company” shall mean any Person who shall be in charge of the maintenance and management of the Ensaara Metropark Amenities and Facilities in the Ensaara Metropark and appointed by the Promoter in accordance with Clause 5.2 hereinbelow. 1.1.17 “Ensaara Metropark Maintenance Charge” shall mean a provisional monthly charge levied, initially by the Promoter and thereafter by the Apex Body or Ensaara Metropark Management Company (as the case maybe), for the management and maintenance of the Ensaara Metropark, calculated on a per square foot/square metre basis of the Total Usable Area of the Unit; as specified in Annexure A and payable by the Allottee for a period of 1 (one) year from the intimation of Possession Date by the Allottee and, thereafter quarterly in advance and/or in the manner as shall be notified by the Promoter to the Allottee or as subsequently decided by the Apex Body or Ensaara Metropark Management Company (as the case may be). 1.1.18 “Ensaara Property” shall mean all that piece and parcel of land admeasuring approximately 54 hectares equivalent to approximately 133 acres situated at Mouja, Pipla Taluka and District Nagpur and more particularly described in the First Schedule hereunder written. 1.1.19 “Floor Space Index” or “FSI” shall mean the quotient obtained by dividing the total covered area (plinth area) on all floors, by the area of the Ensaara Property and more particularly defined in Development Control Regulations, Nagpur, 1991. 1.1.20 “Force Majeure Events” shall mean (a) an act of God such as storm, earthquake, hurricane, tornado, cyclone, flood, adverse weather conditions, etc. or fire (not due to any act, neglect or default of any of the Parties); (b) war, act of terrorism, insurrection, rebellion, riots or other civil unrest; (c) epidemic, pandemic, quarantine restrictions or other public health restrictions or advisories; (d) strikes or lockouts or other labor interruptions; (e) disruption to local, national or international transport services, embargoes resulting in non-availability of materials necessary for the construction of the Building, the failure of any applicable governmental authority to issue any approvals, or the suspension, termination or revocation of any material approvals required for the construction or any acts, orders or legislation of any applicable governmental authority; (f) any notice, order, rule, notification of the Government and / or other public competent authority / Court; or (g) or any other event that is beyond the reasonable control of a Party and which shall directly affect the performance of this Agreement by the affected Party. 1.1.21 “Layout” shall mean construction and development upon the Layout Land of single/multi storied residential building/s in the sole discretion of the Promoter, including the Project. 1.1.22 “Layout Land” shall mean all that piece and parcel of land forming part of the Ensaara Property and which is more particularly described in the Second Schedule hereunder written and shown in blue colour boundary line on the plan annexed hereto as Annexure “C”. 1.1.23 “Permissible Deductions” shall mean (a) an amount equivalent to 10% of the Consideration payable under this Agreement; (b) interest on any overdue payments; (c) brokerage paid to channel partners/brokers, if any; (d) administrative charges as per Promoter’s policy; (e) all taxes paid by the Promoter to the competent authorities; (f) amount of stamp duty and registration charges to be paid on the deed of cancellation of this Agreement, if the Agreement is registered; (g) any other taxes which are currently applicable or may be applicable in future and (h) subvention cost (if the Allottee has opted for subvention plan) which the Promoter may incur either by way of adjustment made by the bank in instalments or paid directly by the Promoter to the bank. 1.1.24 “Possession Date” shall mean the date specified in Annexure A on which date the Promoter shall offer possession of the Unit to the Allottee; subject to the occurrence of any Force Majeure Event and the Allottee complying with all its/his/her obligations under this Agreement. 1.1.25 “Project” shall mean multi-storied building comprising of several units to be constructed on the Project Land and is more particularly described in Annexure A hereto in accordance with the Project Plan. 1.1.26 “Project Land” shall mean a plot of land, being all that piece and parcel of land forming a part of the Layout Land and which is more particularly described in Annexure A hereto and is hereto shown in a red colour boundary line on the plan annexed hereto as Annexure C. 1.1.27 “Project Maintenance Charge” shall mean a provisional monthly charge as specified in Annexure A hereto levied, by the Body Corporate (or Promoter if the Body Corporate is not yet formed) for the management and maintenance of the Project including the common areas of the Project and/or Layout, calculated on a per square foot/square metre basis of the Total Usable Area of the Unit, which shall be paid for a period of 1 (one) year from the intimation of Possession Date by the Allottee and, thereafter quarterly in advance and/or in the manner as shall be notified by the Promoter to the Allottee or as subsequently decided by the Promoter or the Body Corporate (as the case may be). 1.1.28 “Project Plan” shall mean the sanctioned layout plan, as shown in Annexure C hereto, in accordance with which, the Promoter shall construct and develop the Project, on the Project Land and as may be approved by the Appropriate Authorities. 1.1.29 “Promoter’s Project Bank Account” shall mean the bank account, particulars of which are stated in Annexure A. 1.1.30 “Rectification Notice” shall mean a notice issued by the Promoter specifying the delay/defaults by the Allottee in complying with the Allottee's obligations under this Agreement. 1.1.31 “Rectification Period” shall mean a period of 15 (fifteen) days from the date of the Rectification Notice. 1.1.32 “Refund Period” shall mean a period of 30 (thirty) days from the date of execution and registration of the deed of cancellation as stated in accordance with in Clause 11.3.4 hereunder . 1.1.33 “Taxes” shall mean all direct and indirect taxes including but not limiting to the goods and service tax, service tax, value added tax, sales tax, stamp duty, customs and import duties, levy, impost, octroi, and, or, duty of any nature whatsoever, whenever imposed (now or in future) and, or, levied, by any Appropriate Authority, together with any interest and penalties in relation thereto in respect of the Unit, Project/Project Land, Ensaara Metropark and/or Ensaara Property. 1.1.34 “Township Regulations” shall have the meaning ascribed to it in Recital A. 1.1.35 “Unit” shall mean a residential unit in the Project which is more particularly described in Annexure A hereto. 1.1.36 “Unit Amenities and Facilities” shall mean the amenities and facilities to be provided by the Promoter in the Unit and are more particularly stated in Annexure “I” annexed hereto 1.1.37 “Unit Plan” shall mean the sanctioned layout plan, as shown in Annexure G hereto, which includes the sanctioned (and proposed amended floorplans to be approved as the case may be), in accordance with which, the Promoter shall construct and develop the Unit, and as may be approved by the Appropriate Authorities. 1.2 Interpretation 1.2.1 Any reference in this Agreement to any statute or statutory provision shall be construed as including a reference to that statute or statutory provision as from time to time amended, modified, extended or re-enacted whether before or after the date of this Agreement and to all statutory instruments, orders and regulations for the time being made pursuant to it or deriving validity from it. 1.2.2 All references in this Agreement to Articles, Clauses and Sub-Clauses, Schedules or Annexures shall be construed as including a reference to provisions in or to this Agreement unless otherwise specified therein. The words “hereof,” “herein”, “hereto” and “hereunder” and words of similar import when used in this Agreement shall refer to this Agreement as a whole and not to any particular provision in this Agreement. The words “include”, “including” “among other things” and “inter alia” shall be deemed to be followed by “without limitation” or “but not limited to” whether or not they are followed by such phrases, or words of like import. 1.2.3 The headings of the several Articles and Sub-Clauses of this Agreement are intended for convenience only and shall not in any way affect the meaning or construction of any provision therein. 1.2.4 Unless otherwise specifically stated in this Agreement, interest shall mean the State Bank of India highest Marginal Cost of Lending Rate plus two percent. Provided that in case the State Bank of India Marginal Cost of Lending Rate is not in use it would be replaced by such benchmark lending rates which the State Bank of India may fix from time to time for lending to the general public. 1.2.5 Unless otherwise specifically stated in this Agreement, time will be the essence of contract for the purpose of the obligations under this Agreement. 1.2.6 Unless otherwise specifically stated in this Agreement, any amount payable by the Promoter to the Allottee shall be subject to the deduction of Permissible Deductions. 1.2.7 It is hereby expressly recorded that the Recitals hereinabove shall form an integral part of this operative portion, as if the same are set out herein verbatim. 2. AGREEMENT 2.1 The Promoter agrees to develop and construct the Unit as part of the Project to be constructed on the Project Land in accordance with the Unit Plan, as may be amended from time to time in accordance with the disclosures made by the Promoter in Recital G and sanctioned by the Appropriate Authorities under Applicable Laws. 2.2 Subject to and upon the terms, conditions and provisions hereof, including timely payments of all amounts due under this Agreement by the Allottee, the Allottee hereby agrees to purchase from the Promoter and the Promoter hereby agrees to sell to the Allottee on ownership basis the Unit along with the covered/uncovered parking spaces bearing numbers and situated at basement/stilt/podium levels being constructed in the Project as stated in Annexure A and for the consideration as stated in Annexure A. The total aggregate consideration amount for the Unit including the Car parking Spaces is stated in Annexure A. 2.3 The Promoter shall abide by the time schedule for completing the Project and handing over the Unit to the Allottee and the common areas to the Body Corporate in accordance with Clause 7.2 hereinbelow. The Promoter shall handover the Unit to the Allottee on or before the Possession Date subject to the Allottee complying with all the terms and conditions stated herein and making timely payments of the Consideration and other amounts as stated herein. If the Promoter fails or neglects to give possession of the Unit to the Allottee on account of reasons beyond his control and of his agents by the aforesaid date, the Allottee shall have the option to terminate this Agreement and the Promoter shall be liable on demand to refund to the Allottee the amounts already received by it in respect of the Unit with interest from the date the Promoter received the sum till the date the amounts and interest thereon is repaid after deducting therefrom the amount determined as Permissible Deductions. Provided that the Promoter shall be entitled to reasonable extension of time for giving possession of Unit on the aforesaid date, if the completion of Project in which the Unit is to be situated, is delayed on account of Force Majeure Events. In case the Allottee does not exercise his option to terminate this Agreement, the Promoter shall pay to the Allottee, the interest on all the amounts paid by the Allottee, for every month of delay, till the handing over of possession of the Unit. 2.4 The Promoter hereby declares that the FSI available as on date in respect of the Project Land is as per Annexure A only and Promoter has planned to utilize said FSI (including FSI premium, ancillary and TDR if applicable). The Promoter has disclosed the same to be utilized by it on the Project Land in the said Project and Allottee has agreed to purchase the said Unit based on the proposed construction and sale of units to be carried out by the Promoter by utilizing the proposed FSI and on the understanding that the declared proposed FSI shall belong to the Promoter only. Any FSI accruing on the Project Land and/or Layout Land and not being utilised on the Project Land and/or Layout Land, as the case may be, for any reason whatsoever, shall at all times accrue and belong exclusively to the Promoter alone and may be utilised in the Balance Projects at the sole discretion of the Promoter. 2.5 The Allottee acknowledges and confirms that the other units forming part of the Project, the other projects/building/s on the Layout Land and the Balance Projects and/or the plans, layout plans, approvals etc. in respect thereof being implemented or to be implemented in future are not the subject matter of this Agreement and there shall be no right, entitlement or interest of Allottee in respect thereof. 2.6 The Promoter shall be entitled in its sole discretion as it deems to fit to allocate and distribute all vehicle parking spaces in respect of the Project. 3. PAYMENTS 3.1 Consideration 3.1.1 The Allottee shall pay to the Promoter the total aggregate Consideration along with the applicable duties and Taxes as stated in Annexure A as and by way of consideration for sale of the Unit in the Project on what is commonly known as “ownership basis” along with the Car Parking Space. 3.1.2 The Allottee shall pay to the Promoter the Consideration as per the payment schedule as stated in Annexure A hereto. 3.1.3 In addition to the Consideration, the Allottee shall pay all Taxes (whether currently applicable / payable or which may become applicable / payable in future) including but not limited to), Value Added Tax (VAT) and Goods and Services Tax (GST) in connection with the purchase of the Unit. 3.1.4 The Allottee hereby confirms and understands that no third party cheques or RTGS or pay orders will be accepted by the Promoter or considered as payment towards the Consideration and/or the Charges and Deposits. 3.1.5 In compliance with the rules and regulations of the Income Tax authorities, the Allottee shall make all payments towards Consideration or part thereof, after deducting TDS @ 1% (one percent) (or at any other rate that may be prescribed under Applicable Laws) on such amounts, if applicable. Along with such payment, the Allottee shall also be required to submit to the Promoter the requisite challan as well as Form 16 B (presently evidencing payment of TDS to the Government) as per Income Tax Act, 1961, duly executed by the Allottee in that regard. 3.1.6 It is hereby specifically agreed that any payment of the Consideration or part thereof made by the Allottee but is not accompanied with the challan and Form 16B shall be deemed to be a failure to pay and the provisions of clause 3.4 hereinbelow shall apply. 3.1.7 It is hereby further agreed that if Promoter desires so, the Allottee shall authorize the Promoter in writing (by executing such documents as may be necessary), to collect the amount of TDS which the Allottee is liable to deduct and deposit the same with the Appropriate Authorities. The Promoter shall provide Allottee with such documentary proof of deposit, in due course. 3.1.8 The Promoter confirms that the Consideration so stated shall be increased (a) on account of any development charges, levies, duty, cess or any other levy by whatever name called that may be imposed on the Unit and/or the Project and/or Layout by the Appropriate Authorities or (b) on account of any change in the Carpet Area of the Unit as more particularly stated hereinbelow. In such an event the Allottee agrees to pay the additional amount to the Promoter without protest or demur before the handover of the Unit to the Allottee. If there is any reduction in the Carpet Area of the Unit within the defined limit, then the Promoter shall refund the excess money paid by Allottee within 45 (forty-five) days with the annual interest calculated from the date when such an excess amount was paid by the Allottee.. 3.1.9 The Allottee confirms that he/she/they/it has/have voluntarily and willingly paid the booking amounts and other instalments of the Consideration to the Promoter on or prior to the execution of this Agreement. 3.2 Charges and Deposits 3.2.1 In addition to the Consideration, the Allottee shall pay and/or deposit with the Promoter on demand, the Charges and Deposits as specified in Annexure A hereto, on or before the Possession Date in the Charges and Deposits Bank Account. 3.2.2 The Promoter shall be entitled, in its discretion, to appropriate and/or adjust monies held for one purpose and/or on one account, against any liabilities due and payable herein by the Allottee for any other purpose or any other account. The Promoter shall maintain separate books of account in respect of the Charges and Deposits, collected in advance and shall be liable to render the accounts of such Charges and Deposits, only to the Body Corporate and/or Apex Body, as the case may be, and not individually to the Allottee at any time. The Charges and Deposits, paid to the Promoter by the Allottee shall not carry any interest and the same shall remain with the Promoter until the formation of the Body Corporate and/or Apex Body and only after utilizing, appropriating and adjusting the same, be transferred by the Promoter to the Body Corporate and/or the Apex Body, as the case may be. 3.2.3 The amounts of Charges and Deposits have been separately agreed to and recorded in writing and signed by the Parties and shall form part of this Agreement. 3.3 Project Maintenance Charge and Ensaara Metropark Maintenance Charge 3.3.1 The Allottee shall be liable to pay to the Promoter and/or the Body Corporate (as the case may be) the Project Maintenance Charge as shall be decided and/or specified in Annexure A, being the charges for a period of 1 (one) year and, thereafter the same shall be paid quarterly in advance to the Promoter or the Body Corporate (as the case may be) or as may be varied from time to time. The Promoter and/or the Body Corporate (as the case may be) shall 1 (one) month prior to the expiry of the preceding quarter raise bills for the same or as may be varied from time to time. 3.3.2 Upon the Allottee receiving the Notice of Possession and prior to taking the possession of the Unit, the Allottee shall pay to the Promoter and/or the Apex Body (as the case may be) the Ensaara Metropark Maintenance Charge as specified in Annexure A, being the charges for a period of 1 (one) year and, thereafter, the Allottee shall be liable to pay the Ensaara Metropark Maintenenance Charge quarterly in advance to the Promoter or the Apex Body (as the case may be) as may be varied and notified to the Allottee from time to time. The Promoter and/or the Apex Body (as the case may be) shall 1 (one) month prior to the expiry of the preceding quarter raise bills for the same as may be varied from time to time. 3.3.3 If in the event the Promoter is responsible for collecting the Project Maintenance Charge and/or Ensaara Metropark Maintenance Charge and there being any arrears in payment of the same by the Allottee, the Promoter shall before transferring over such Project Maintenance Charge and/or Ensaara Metropark Maintenance Charge to the Body Corporate or the Apex Body (as the case maybe), appropriate the shortfall from and out of the Project Maintenance Charge and/or Ensaara Metropark Maintenance Charge and/or Building Sinking Fund collected from all the other unit allottees who may be member of the same Body Corporate and/or the Apex Body, as the case may be, and shall recover the same along with interest due (if any) from the Allottee. 3.3.4 If the Project Maintenance Charge and/or Ensaara Metropark Maintenance Charge, which is charged on a provisional basis, is insufficient to manage and maintain the Project and/or Ensaara Metropark then in that event the Promoter, Body Corporate and/or Apex Body, as the case may be, shall have the right to increase the Project Maintenance Charge and/or Ensaara Metropark Maintenance Charge from time to time and the Allottee shall without any protest pay its proportionate share of such increase. 3.3.5 The Allottee agrees to pay the Project Maintenance Charge and/or Ensaara Metropark Maintenance Charge within 15(fifteen) days from the date of demand thereof by the Promoter, Body Corporate and/or Apex Body as the case may be. Any delay in payment of either the Project Maintenance Charge and/or Ensaara Metropark Maintenance Charge shall make the Allottee liable to pay interest at the rate of 18% p.a from the date the said amount becoming due and payable by the Allottee to the Promoter, Body Corporate and/or Apex Body as the case may be, till the date of realization such amount. 3.3.6 If the Allottee does not pay the Project Maintenance Charge and/or Ensaara Metropark Maintenance Charge and interest thereon (if any) for a period of more than 2 (Two) quarters consecutively then in that event the Promoter, the Body Corporate and/or the Apex Body (as the case may be) shall have the right to withhold or cut-off the amenities or facilities or services enjoyed by the Allottee in relation to the Unit, Project and/or Ensaara Metropark. However the liability to pay Project Maintenance Charge and/or Ensaara Metropark Maintenance Charge along with interest thereon shall continue irrespective of the discontinuance of such amenities or facilities or services. 3.3.7 In the event any of the utility providers are unable to provide any of its services in respect of the Unit Amenities and Facilities or Ensaara Metropark Amenities and Facilities, then in that event the Promoter, Body Corporate and/or Apex Body as the case may be, shall not be liable or responsible to provide the same. 3.4 Timely Payments 3.4.1 Time, for payment of all the instalments of the Consideration, Charges and Deposits, Project Maintenance Charge and/or Ensaara Metropark Maintenance Charge and other amounts payable by the Allottee under this Agreement is of the essence of this Agreement. It is hereby expressly clarified, agreed and understood that if for any reason whatsoever, the Allottee commits any delay and/or default in payment of any of the amounts mentioned in this Agreement or in providing the challan and Form 16B evidencing the TDS deducted then in such event, without prejudice to the other rights and remedies available to the Promoter, the Allottee shall be liable to pay to the Promoter interest as per Applicable Law on the amount of the instalment/s and/or other amounts from their respective due dates till payment and/or realization. 3.4.2 Without prejudice to the provisions of sub-clause 3.4.1 above, in the event the Allottee commits default in payment on due date of any amount due and payable by the Allottee under this Agreement (including his/her/their/its proportionate share of Taxes levied by concerned local authority and other outgoings) and on the Allottee committing 3 (three) defaults of payment of instalments, the Promoter shall at his own option, may terminate this Agreement. Provided that, Promoter shall give notice of 15 (fifteen) days in writing to the Allottee, by Registered Post with A.D. at the address provided by the Allottee and mail at the e-mail address provided by the Allottee, of its intention to terminate this Agreement and of the specific breach or breaches of terms and conditions in respect of which it is intended to terminate the Agreement. If the Allottee fails to rectify the breach or breaches mentioned by the Promoter within the period of notice then at the end of such notice period, Promoter shall be entitled to terminate this Agreement and to the consequences of termination as stated in Clause 11.3 hereunder shall follow. 3.4.3 All payments as provided in this Agreement shall be made by the Allottee by way of cheque/demand draft/pay order drawn in favour of the Promoter’s Project Bank Account or the Charges and Deposits Bank Acocunt or in such other manner as may be notified by the Promoter. In the event the Promoter desires that the cheques/demand drafts/pay orders be drawn in favour of another bank account, the Promoter shall inform the Allottee of the same in writing, and upon receipt of such written intimation from the Promoter, the Allottee shall make all future payments accordingly. 3.4.4 The Allottee, if resident outside India, shall be solely responsible for complying with the necessary formalities as laid down in Foreign Exchange Management Act, 1999, Reserve Bank of India Act, 1934 and the rules and regulations framed there under (“Foreign Exchange Laws”) or any statutory amendment(s), modification(s) made thereof and all other Applicable Laws including that of remittance of payment acquisition/sale/transfer of immovable properties in India etc. and provide the Promoter with such permission, approvals which would enable the Promoter to fulfil its obligations under this Agreement. Any refund, transfer of security, if provided in terms of this Agreement shall be made in accordance with the Foreign Exchange Laws or any other Applicable Laws. The Allottee understands and agrees that in the event of any failure on his/her/its part to comply with the applicable guidelines issued by the Reserve Bank of India, he/she/it shall be liable for any actions under the Foreign Exchange Laws or other laws as applicable, as amended from time to time. The Allottee shall keep the Promoter fully indemnified and harmless in this regard. Wherever there is any change in the residential status of the Allottee subsequent to the signing of this Agreement, it shall be the sole responsibility of the Allottee to intimate the same in writing to the Promoter immediately and comply with necessary formalities, if any, under the Foreign Exchange Laws or any other Applicable Laws. The Promoter shall not be responsible towards any third-party making payment/remittances on behalf of the Allottee and such third party shall not have any right in the application/allotment of the Unit applied for herein, in any way and the Promoter shall be issuing the payment receipts in favour of the Allottee only. 3.4.5 The Allottee shall be completely responsible for any notices or actions taken by any of the authorities due to non-compliances of the Foreign Exchange Laws by the Allottee and the Promoter shall not be in any case responsible for the same. 3.4.6 The Promoter shall have first and paramount charge and lien on the Unit and Car Parking Space in respect of any amount whatsoever payable by the Allottee to the Promoter under this Agreement. The Allottee shall not object to or dispute the aforesaid for any reason whatsoever and the Allottee hereby irrevocably and unconditionally consents to the aforesaid and agrees and undertakes to pay all the amounts on time. 3.4.7 It is hereby agreed that if due to any ordinance, notification, change in existing laws or enactments, any additional Taxes, levies, service tax or VAT, Goods or Services tax, or any other Taxes/charges/surcharge pertaining or relating to the sale of the Unit and/or to the development, construction of the Unit, Project and/or Ensaara Metropark are levied or increased and are payable by the Promoter and/or recovered from the Promoter, then the same shall be borne and paid by the Allottee, at actuals, without any objection. Provided that the Promoter shall enclose the said notification/order/rule/regulation published /issued in that behalf to that effect along with the demand letter being issued to the Allottee, which shall only be applicable on subsequent payments or as specified in the said notification. 3.4.8 The Promoter shall be entitled, in its discretion, to appropriate and/or adjust monies held for one purpose and/or on one account, against any liabilities due and payable herein by the Allottee for any other purpose or any other account. Any overdue payments so received will be first adjusted against interest accrued then towards statutory dues and subsequently towards outstanding dues of the Allottee. 4. CONSTRUCTION AND DEVELOPMENT 4.1 Ensaara Metropark 4.1.1 The Ensaara Metropark together with the Ensaara Metropark Amenities and Facilities, is and shall be undertaken and implemented by the Promoter as it deems fit, in its sole discretion subject to the occurrence of any event of Force Majeure. No persons or parties, including the Allottee and the Body Corporate shall interfere, obstruct the Promoter in the development and construction of the Ensaara Metropark. 4.1.2 Notwithstanding anything contained herein, the Promoter, shall in its discretion, inter alia, be entitled to make any variations, alterations, amendments or deletions in respect of the layout and planning of the Ensaara Metropark or any of the Balance Projects, without recourse to the Allottee. Further the Promoter has disclosed and explained to the Allottee that in accordance with the Township Regulations, the Project Plan and/or Layout Plan shall, without affecting the Unit, be amended/modified in order to utilize the extra FSI permitted. The Promoter shall also be entitled to delete/de-notify all or part of Ensaara Metropark from the Township Regulations at any point in time. In such case of such deletion/denotificaton, the Allottee shall acknowledge and accept the same without any protest or demur. Further, the Allottee hereby agrees that he/she/it shall not have any claim against the Promoter in relation to such deletion/denotification. The Allottee shall have no claim whatsoever on any such denotified and/or deleted portion of Ensaara Metropark. The Allottee understands and irrevocably consents to the same. 4.1.3 The Promoter shall develop several other amenities like neighbourhood clubs, convenience stores etc. either for the exclusive use of all the allottees of the Project or to be shared with the allottees of the Balance Projects as maybe decided by the Promoter in its sole discretion. The details of the neighbourhood club, if any, including the exclusive or non-exclusive use by all the allottees of the Project and/or the Balance Projects, as the case maybe, and the consideration to be paid in respect thereof, if any, are more particularly stated in Annexure A. 4.1.4 The Allottee understands that use of all such amenities shall always be subject to the rules and regulations that may be framed by the Promoter and/or Apex Body from time to time. 4.1.5 For the proper upkeep, maintenance and security of parks and recreation grounds in Ensaara Metropark, the Promoter, the Apex Body and/or Ensaara Metropark Management Company shall be entitled to charge an entrance fee and restrict the timing of its use and access. 4.2 Layout 4.2.1 The Layout is and shall be undertaken and implemented by the Promoter as it deems fit, in its sole discretion subject to the occurrence of any event of Force Majeure. No persons or parties, including the Allottee and the Body Corporate shall interfere, obstruct the Promoter in the development and construction of the Layout excluding the Project. 4.3 Project and Unit 4.3.1 The Promoter shall construct the Project including the Unit, on the Project Land in accordance with the Project Plan and shall commence/ has commenced construction work of the Project. 4.3.2 The Promoter shall provide with the Unit purchased by the Allottee, the Unit Amenities and Facilities, as stated in Annexure H annexed hereto. For quality control purposes and/or due to non-availability or short supply of any of the Unit Amenities and Facilities and/or materials or items used or comprised therein, the said Unit Amenities and Facilities may be altered, amended or substituted with materials or items or brands of a similar nature. 4.3.3 The Promoter shall confirm the final carpet area that has been allotted to the Allottee after the construction of the Project is complete and the occupancy certificate is granted by the Appropriate Authority, by furnishing details of the changes, if any, in the carpet area, subject to a variation cap of 3% (three percent). The total price payable for the carpet area shall be recalculated upon confirmation by the Promoter. If there is any reduction in the carpet area within the defined limit then Promoter shall refund the excess money paid by Allottee within 45 (forty-five) days with the interest, from the date when such an excess amount was paid by the Allottee. If there is any increase in the carpet area allotted to Allottee, the Promoter shall demand additional amount from the Allottee as per the next milestone of the payment details as provided in Annexure A. All these monetary adjustments shall be made at the same rate per square meter as agreed in this Agreement. 4.4 Completion of the Project and Unit 4.4.1 The Promoter shall offer the possession of the Unit to the Allottee on the Possession Date. The Promoter shall give a written notice to the Allottee 7 (seven) days prior to the Possession Date (“Notice of Possession”) for the Allottee to take possession of the Unit and within 2 (two) months from the date of issue of such notice the Allottee shall take possession. It is hereby clarified that the aforementioned notice shall be issued only after the Promoter obtains occupancy certificate with respect to the Project from the relevant Appropriate Authority. 4.4.2 Upon receiving a written intimation from the Promoter, the Allottee shall take possession of the Unit and execute necessary indemnities, undertakings and such other documentation as may be required for taking possession of the Unit. In case the Allottee fails to take possession within the aforementioned time period of 2 (two) months, the Allottee shall be liable to pay the Ensaara Metropark Maintenance Charge and the Project Maintenance Charge from the Possession Date. 4.5 Defects 4.5.1 If the Allottee brings to the notice of the Promoter any structural defect in the Unit within a period of 5 (five) years or as may be amended from time to time under the relevant laws, on account of workmanship, quality or provision of service, then it shall wherever possible be rectified by the Promoter without further charge to the Allottee. 4.5.2 After the Possession Date, any damage due to wear and tear of whatsoever nature is caused to thereto (save and except the defects as mentioned in Clause 4.5.1 above), the Promoter shall not be responsible for the cost of re-instating and/or repairing such damage caused by the Allottee and the Allottee alone shall be liable to rectify and reinstate the same at his/her/its/their own costs. 4.5.3 It is however expressly agreed that due to changes made by the Allottee in the Unit or other allottees of the units in the Project, if any complaint arises, then in such circumstances the Promoter shall not be liable or responsible for repairs. Further, if any defect, damage or destruction is caused due to storm, earthquake, hurricane, tornado, cyclone, flood, adverse weather conditions or fire or any other Force Majeure Event, or any act or omission by the occupants of the neighboring land and/or any Government or local authority, then in such circumstances the Promoter shall not be liable or responsible for repairs. Furthermore, if any defect or damage is found to have been caused due to the negligence of the Allottee or any other allottees or his/her/its agents or structural defects caused or attributable to the Allottee including by carrying out structural or architectural changes from the original design attributes demolition, dismantling, making openings, removing or re-sizing the original structural framework, putting excess or heavy load or using the Unit other than for its intended purpose or such other reasons attributable to the Allottee or any other allottees or his/her/its agents, then the Promoter shall not be liable for the same. 4.5.4 It is expressly agreed that any additional work which is requested by the Allottee and executed by the Promoter on behalf of the Allottee, which is not a part of the standard structure, equipment, fittings, layout, materials etc. being provided by the Promoter in general, will not be considered a part of the warranty or cannot be claimed in any manner whatsoever under the defect liability claim. Also, such modifications, alterations, changes etc. will not be allowed to be executed or implemented unless the same has been approved by the Structural Engineer, Architect and Project Engineer appointed by the Promoter. 5. MANAGEMENT AND MAINTENANCE 5.1 Management and Maintenance of the Project 5.1.1 For the purposes of management and maintenance of the Project, the Promoter shall at the appropriate time as per Applicable Law, form and register a Body Corporate comprising of all the unit allottees of the Project including the Allottee and upon such Body Corporate being constituted the internal management, maintenance and security of the Project shall be the sole responsibility of the Body Corporate. 5.1.2 The Promoter and/or the Body Corporate either directly or by appointing a professional management company which shall be in charge of the maintenance, management and upkeep of the Project and all its limited common areas, amenities and facilities. 5.1.3 The Project Maintenance Charge shall be paid by the Allottee to the Promoter and/or the Body Corporate (as the case may be) in accordance with clause 3. 5.2 Management and Maintenance of Ensaara Metropark 5.2.1 The Allottee understands that as per the Township Regulations, the Promoter is responsible for the overall management and maintenance of Ensaara Metropark until an urban local body/Apex Body is constituted for the Ensaara Metropark by the Appropriate Authorities and accordingly Ensaara Metropark shall be managed and maintained by the Promoter directly or indirectly by the Apex Body/Ensaara Metropark Management Company. The Allottee hereby agrees and gives consent to the appointment of the Ensaara Metropark Management Company by the Promoter for purposes of management and maintenance of Ensaara Metropark. 5.2.2 The Promoter, Apex Body and/or the Ensaara Metropark Management Company shall be in charge of the maintenance, management and upkeep of the sewerage treatment plant, garbage disposal system, roads, street lights landscapes, parks, security, housekeeping and such other facilities that the Promoter may be required to install, build, operate and maintain under the guidelines prescribed under the Township Regulations and/or any other statute, rules and regulations as may be framed by the Appropriate Authorities and for such annual fees, which fees shall be a minimum of 20% (twenty percent) (and escalation thereto) over and above the actual annual expenses that may be incurred by the Ensaara Metropark Management Company. The said fees shall be paid to the Ensaara Metropark Management Company on a quarterly basis. 5.2.3 It is hereby expressly clarified, agreed and understood that until the formation and constitution of the urban local body as per the Township Regulations or if informed by the Promoter on part/all deletion/denotification from the Township Regulations, the Promoter and/or the Ensaara Metropark Management Company shall be entitled to exercise their rights under this Agreement, notwithstanding the formation of the Apex Body. The Allottee is deemed to have given consent for confirming such agreement or contract that has been/may be entered into by the Promoter with the Ensaara Metropark Management Company for the effectual management and maintenance of Ensaara Metropark. In the event of any act, deed, matter or thing committed or omitted to be done by the Ensaara Metropark Management Company in due course of such maintenance, management, control and regulation of Ensaara Metropark, only the Ensaara Metropark Management Company shall be held accountable, liable or responsible in any manner whatsoever to the Allottee, the Apex Body and/or the Body Corporate. 6. CONDITIONS 6.1 The Unit agreed to be sold by the Promoter to the Allottee is subject to the following: 6.1.1 The Unit is to be used for residential purposes only. 6.1.2 All schemes, rules and regulations and bye-laws affecting or in respect of the Ensaara Metropark, Project, Layout, Unit or any part/s thereof, shall be prescribed, formulated and/or modified by the Body Corporate and/or Apex Body, as the case maybe, from time to time and the Allottee hereby agrees to abide by the same without any demur. The same shall also apply to all the terms, conditions, covenants, provisions, stipulations and restrictions contained in all the orders, sanctions, permissions and approvals granted and/or given and to be granted and/or given by the Appropriate Authorities. In the event of the Allottee doing or committing any act, deed or thing in contravention of the above, the Allottee shall be responsible and liable for the consequences thereof to the Promoter, the Body Corporate, the Apex Body and/or the Appropriate Authorities. 6.1.3 The terms, conditions, covenants, stipulations and provisions contained in all the agreements, deeds, documents and writings executed or to be executed by and between the Promoter and their predecessors-in-title of the Ensaara Property and the Allottee hereby agrees to abide by the same without any demur. 6.1.4 The terms, conditions, covenants, stipulations, provisions and restrictions as have been and may hereafter be specified and required by the Promoter in their sole and unfettered discretion, for the more beneficial and optimum use and enjoyment of Ensaara Metropark and/or the Ensaara Property, and the buildings and structures constructed and/or to be constructed thereon by the Promoter and/or their associate and/or group concern/s, on the Ensaara Property, including all or any of the Ensaara Metropark Amenities and Facilities and/or all or any common and/or limited common areas, amenities and facilities of the Project in and relating to the same, whether generally or for the benefit and enjoyment of any particular allottees and/or transferee/s and/or allottee/s and/or any particular class or classes of allottees, transferees and/or allottees of the Ensaara Property. 6.1.5 The express right, authority and entitlement of the Promoter to give and/or grant over, upon and/or in respect of the Ensaara Property and/or any construction thereon or any portion/s thereof, all rights, interests, benefits, privileges and easements, in favour of any person/s whatsoever including the owners and occupiers of the Ensaara Property and any contiguous, adjoining or adjacent properties, on such terms, conditions and provisions and as may be desired or deemed necessary by the Promoter in their sole and unfettered discretion and/or as may be required by any Appropriate Authority. This right, authority and entitlement of the Promoter shall include, but without any limitation, the right to give and/or grant right of way and access, right to light and air, right to draw from or connect to, as the case may be, water drainage, sewage, electricity, gas and telephone lines and/or connections and/or installations and all and/or any other facilities, utilities and amenities on the Project Land and/or the Ensaara Property and/or any construction thereon including in the Project and/or in Ensaara Metropark; including the right to give and/or grant or permit the use and enjoyment of all or any of the areas, amenities and/or facilities of, provided in and/or relating to the Ensaara Property and/or any construction thereon or any part thereof; provided that in exercising its rights the Promoter shall ensure that the Unit is not hindered/obstructed in any manner. 6.1.6 Any modifications or amendments that may be necessary to the layout of the Ensaara Metropark, in lieu of what is stated in Recital G and that the Promoter shall not liable to pay any amount whatsoever, to the Allottee in respect of any damages, loss, costs, charges etc that the Allottee may suffer on account of the same. 6.1.7 The Allottee hereby expressly, irrevocably and unconditionally consents to the provisions of Clause 6 herein and hereby undertakes that the Allottee shall not raise any objection or dispute whatsoever in respect of the aforesaid and the Allottee shall be bound and liable to render all assistance to and co-operate with the Promoter in respect thereof as may be required by the Promoter from time to time and the Allottee shall do and perform all acts, deeds and things, including to sign and execute all documents and writings, in this regard as may be required by the Promoter. 7. TRANSFER TO BODY CORPORATE AND/OR APEX BODY 7.1 Formation of Body Corporate The Promoter shall enable the formation of the Body Corporate within a period of three months of the majority of allottees having booked their units in the Project or as per Applicable Law.